Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Default by Lessor Lessor shall not be in default unless Lessor fails to perform obligations required of Lessor within a reasonable time, but in no event later than thirty (30) days after written notice by Lessee to Lessor and to the holder of any first mortgage or deed of trust covering the Premises whose name and address shall have theretofore been furnished to Lessee in writing, specifying wherein Lessor has failed to perform such obligation; provided, however, that if the nature of Lessor's obligation is such that more than thirty (30) days are required for performance then Lessor shall not be in default if Lessor commences performance within such 30-day period and thereafter diligently prosecutes the same to completion.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant’s Default 14.1 Any other provisions in this Lease notwithstanding, it shall be an event of default (“Event of Default”) under this Lease if: (i) Tenant fails to pay any installment of rent or any other sum payable by Tenant hereunder when due and such failure continues for a period of ten (10) days after written notice from Landlord to Tenant that such payment has not been received, or (ii) Tenant fails to observe or perform any other material covenant or agreement of Tenant herein contained and such failure continues after written notice given by or on behalf of Landlord to Tenant for more than thirty (30) days, provided, however, that if such non-monetary Event of Default by Tenant cannot reasonably be cured within such thirty (30) day period, and provided further that Tenant is proceeding with due diligence to effect a cure of said Event of Default, no Event of Default hereunder shall be declared by Landlord if Tenant continues to proceed with diligence to cure said Event of Default, but in no event shall such cure period extend beyond ninety (90) days following notice from Landlord of such violation, default or breach, or (iii) Tenant files a petition commencing a voluntary case, or has filed against it a petition commencing an involuntary case, under the Federal Bankruptcy Code (Title 11 of the United States Code), as now or hereafter in effect, or under any similar law, or files or has filed against it a petition or answer in bankruptcy or for reorganization or for an arrangement pursuant to any state bankruptcy law or any similar state law, and, in the case of any such involuntary action, such action shall not be dismissed, discharged or denied within sixty (60) days after the filing thereof, or Tenant consents or acquiesces in the filing thereof, or (iv) a custodian, receiver, trustee or liquidator of Tenant or of all or substantially all of Tenant’s property or of the Premises shall be appointed in any proceedings brought by or against Tenant and, in the latter case, such entity shall not be discharged within sixty (60) days after such appointment or Tenant consents to or acquiesces in such appointment, or (v) Tenant shall generally not pay Tenant’s debts as such debts become due, or shall make an assignment for the benefit of creditors, or shall admit in writing its inability to pay its debts generally as they become due. The notice and grace period provisions in clauses (i) and (ii) above shall have no application to the Events of Default referred to in clauses (iii) through (v) above.
14.2 If Tenant shall fail to make any payment of rent when due or if Tenant shall fail to keep and perform any express written covenant of this Lease and shall continue in default for a period of ten (10) days after Tenant has received written notice of such default and demand of performance from Landlord, Landlord may commence judicial proceedings, provided, however, if any default shall occur (other than in the payment of rent) which cannot be cured within a period of thirty (30) days and Tenant, prior to the expiration of thirty (30) days from and after the giving of notice as aforesaid, commences to eliminate such default and proceeds diligently to take steps to cure the same, Landlord shall not have the right to declare the term ended by reason thereof for an additional period of sixty (60) days.
14.3 In the event of any such Event of Default, Landlord at any time thereafter may at its option exercise any remedies available to Landlord at law or in equity, including, without limitation, one or more of the following remedies:
Default by Lessee If Lessee fails to make payment of any Monthly Rental within five days of delivery by Lessor of notice of any Monthly Rental that is past due, or fails to cure any other default under this Agreement within ten days of delivery by Lessor of such default, then a “Lessee Event of Default” shall exist and Lessor shall have the following remedies, which shall be cumulative rather than exclusive:
(a) the right to terminate this Agreement, and the grant of the Lease hereunder, which termination right may be exercised by written notice by Lessor to Lessee, and which termination shall be effective as of the date of such notice;
(b) the right to immediately enter upon and repossess the Designated Boat Slip and all appurtenances thereto, by forcible entry and detainer suit, or otherwise;
(c) the right to remove Lessee’s Craft (and any personal property then inside Lessee’s Craft from its mooring, and to store Lessee’s Craft (and such personal property), with all risk of loss belonging solely to Lessee, and with no liability whatsoever to Lessor, and with all costs of storage being deemed to be including among the past due Monthly Rental under this Agreement;
(d) the right to make any required repairs to the Designated Boat Slip, or to expend any other sums required to cure any defaults by Lessee under this Agreement, with all such sums expended being deemed to be included among the past due Monthly Rental under this Agreement;
(e) the right to terminate Lessee’s rights of possession with regard to the Designated Boat Slip and all appurtenances thereto, without demand or notice of any kind and without terminating this Agreement, in which event Lessor may, but shall be under no obligation to, relet all or any part of the Designated Boat Slip for credit to Lessee’s account, on such terms and conditions as Lessor in its sole discretion shall deem appropriate; and
(f) the right to exercise Lessor’s rights under the Texas Uniform Commercial Code with regard to the security interest granted to Lessor in the Secured Property. In the event of any Lessee Event of Default, Lessor shall have the right to recover from Lessee, whether by way of sale of the Secured Property, or by means of execution and levy on a judgment, or by means of voluntary payment by Lessee, or by some combination thereof: (a) all Monthly Rental that is past due, including any late payment fees due in connection therewith, (b) all Monthly Rental to come due during the remainder of the Term (assuming that Lessor has not terminated this Agreement and the Lease hereunder), (c) Lessor’s reasonable and necessary attorneys’ fees and costs of court, (d) pre-judgment at the lesser of 8% per annum or the maximum allowed by law, and (e) post-judgment interest at lesser of 10% per annum or the maximum allowed by law.
CURING TENANT'S DEFAULTS If Tenant defaults in the performance of any of its obligations under this Lease, Landlord may (but shall not be obligated to) without waiving such default, perform the same for the account at the expense of Tenant. Tenant shall pay Landlord all costs of such performance promptly upon receipt of a xxxx therefor.
Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.
Default by Tenant 14.1 The following shall be deemed a default by Tenant under the terms of the Lease (“Event of Default”):
a. The failure by Tenant to pay any rent or other sum of money due hereunder within ten (10) days after written notice from Landlord that such payment has not been made;
b. The failure by Tenant to perform any other of the terms, conditions or covenants of this Lease to be observed or performed by Tenant for more than thirty (30) days after written notice from Landlord of such default, unless such default is of a nature that it cannot practicably be cured within a thirty (30) day period and Tenant is proceeding with due diligence to cure such default;
c. The making by Tenant of an assignment for the benefit of creditors;
d. The filing of a petition by or against Tenant for adjudication as a bankrupt under the Bankruptcy Act, as now or hereafter amended or supplemented, or for reorganization within the meaning of Chapter XI of the Bankruptcy Act, or the commencement of any action or proceeding for the dissolution or liquidation of Tenant, whether instituted by or against Tenant, or for the appointment of a receiver or trustee of the property of Tenant, provided that no such filing or proceeding instituted by a third party shall be regarded as a default hereunder if Tenant shall promptly move to have the same dismissed, rescinded or rendered inoperative and Tenant prosecutes such action with due diligence and continues to perform and discharge all of the covenants and obligations on its part to be performed or discharged under this Lease during the pendency of such proceedings.
14.2 Upon the occurrence of an Event of Default, Landlord shall have the immediate right of re-entry and possession of the Leased Premises, which right shall remain continuous until such time as Tenant shall have cured such Event of Default. Notwithstanding such re-entry and possession of the Leased Premises by Landlord, Tenant shall remain liable for the rent and other sums payable hereunder whether or not the Leased Premises are relet by Landlord an for all expenses which Landlord may incur in re-entering the Leased Premises and repairing and maintaining the same less such proceeds, if any, which may result from the reletting of the Leased Premises.
14.3 Additionally, upon the occurrence of any Event of Default, Landlord shall have the right to terminate this Lease by written notice of such intention to Tenant. In the event Landlord elects to terminate this Lease, Tenant’s liability for rent and other sums payable hereunder and to perform any other term, condition, covenant or agreement on its part to be performed under this Lease shall cease and terminate as to any period subsequent to the date on which Landlord delivers to Tenant written notice of such termination. Tenant shall remain liable, however, for all rent and the performance of all terms conditions and agreements relating to matters prior to the date of such termination.
14.4 Additionally, the parties agree that any default by the co-tenant, SenCer, Inc. can be treated by Landlord as a default by Tenant as though it was Tenant’s own default. Tenant will be given the opportunity to cure such default under the terms of this Agreement. Failure of Tenant to successfully cure said default shall give Landlord the right to implement any remedy authorized under the terms of this agreement.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
(a) The failure by Tenant to make any payment of rent or additional rent required to be made by Tenant, as amid when due, where the failure continues for a period of five (5) days after written notice from Landlord to Tenant; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. For purposes of these default and remedies provisions, the term “additional rent” shall be deemed to include all amounts of any type whatsoever other than Basic Rent to be paid by Tenant pursuant to the terms of this Lease.
(b) Assignment, sublease, encumbrance or other transfer of the Lease by Tenant, either voluntarily or by operation of law, whether by judgment, execution, transfer by intestacy or testacy, or other means, without the prior written consent of Landlord.
(c) The discovery by Landlord that any financial statement provided by Tenant, or by any affiliate, successor or guarantor of Tenant, was materially false.
(d) The failure of Tenant to timely and fully provide any subordination agreement, estoppel certificate or financial statements in accordance with the requirements of Article XIII.
(e) The failure or inability by Tenant to observe or perform any of the express or implied covenants or provisions of this Lease to be observed or performed by Tenant, other than as specified in any other subsection of this Section, where the failure continues for a period of thirty (30) days after written notice from Landlord to Tenant or such shorter period as is specified in any other provision of this Lease; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. However, if the nature of the failure is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall not be deemed to be in default if Tenant commences the cure within thirty (30) days, and thereafter diligently pursues the cure to completion.
(i) The making by Tenant of any general assignment for the benefit of creditors; (ii) the filing by or against Tenant of a petition to have Tenant adjudged a Chapter 7 debtor under the Bankruptcy Code or to have debts discharged or a petition for reorganization or arrangement under any law relating to bankruptcy (unless, in the case of a petition filed against Tenant, the same is dismissed within thirty (30) days); (iii) the appointment of a trustee or receiver to take possession of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, if possession is not restored to Tenant within thirty (30) days; (iv) the attachment, execution or other judicial seizure of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, where the seizure is not discharged within thirty (30) days; or (v) Tenant’s convening of a meeting of its creditors for the purpose of effecting a moratorium upon or composition of its debts. Landlord shall not be deemed to have knowledge of any event described in this subsection unless notification in writing is received by Landlord, nor shall there be any presumption attributable to Landlord of Tenant’s insolvency. In the event that any provision of this subsection is contrary to applicable law, the provision shall be of no force or effect.
