Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Time Limits for Submission of Claim Failure by Purchaser to submit a Claim within established time limits shall relinquish the United States from any and all obligations whatsoever arising under the contract or portions thereof. Purchaser shall file such Claim within the following time limits: (a) When Purchaser constructs Specified Road, Pur- chaser must file any Claim not later than 60 days after re- ceipt of Forest Service written notification of acceptance; (b) When Forest Service constructs Specified Road, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification authorizing use of road; (c) For subdivisions or cutting units, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification that subdivision or cutting unit has been accepted; and (d) In all other cases, Purchaser must file any Claim not later than 60 days after receipt of Contracting Officer written notification that timber sale is closed.
Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.
Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.
Resolution of Claims The Company acknowledges that a settlement or other disposition short of final judgment may be successful on the merits or otherwise for purposes of Section 8(a)(i) if it permits a party to avoid expense, delay, distraction, disruption and uncertainty. In the event that any Claim relating to an Indemnifiable Event to which Indemnitee is a party is resolved in any manner other than by adverse judgment against Indemnitee (including, without limitation, settlement of such action, claim or proceeding with our without payment of money or other consideration) it shall be presumed that Indemnitee has been successful on the merits or otherwise for purposes of Section 8(a)(i). The Company shall have the burden of proof to overcome this presumption.
Claims Submission Unless otherwise prohibited by federal or state law, Provider will submit Clean Claims for all Covered Services to BCBSM within one hundred eighty (180) days of the date of service.
Notification of Claims (a) Except as otherwise provided in this Agreement, a Person that may be entitled to be indemnified under this Agreement (the “Indemnified Party”), shall promptly notify the party liable for such indemnification (the “Indemnifying Party”) in writing of any pending or threatened claim, demand or circumstance that the Indemnified Party has determined has given or would reasonably be expected to give rise to a right of indemnification under this Agreement (including a pending or threatened claim or demand asserted by a third party against the Indemnified Party, such claim being a “Third Party Claim”), describing in reasonable detail the facts and circumstances with respect to the subject matter of such claim, demand or circumstance (a “Claim Notice”); provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article XI except to the extent the Indemnifying Party is prejudiced by such failure, it being understood that notices for claims in respect of a breach or inaccuracy of a representation or warranty or breach of or default under any obligation or covenant must be delivered before the expiration of any applicable survival period specified in Section 11.4(a). (b) Upon receipt of a notice of a claim for indemnity from an Indemnified Party pursuant to Section 11.5(a) with respect to any Third Party Claim, the Indemnifying Party shall have the right (but not the obligation) to assume the defense and control of any Third Party Claim upon written notice to the Indemnified Party delivered within fifteen (15) Business Days of the Indemnifying Party’s receipt of the applicable Claim Notice and, in the event that the Indemnifying Party shall assume the defense of such claim, it shall allow the Indemnified Party a reasonable opportunity to participate in the defense of such Third Party Claim with its own counsel and at its own expense. The Person that shall control the defense of any such Third Party Claim (the “Controlling Party”) shall select counsel, contractors and consultants of recognized standing and competence after consultation with the other party and shall take all steps reasonably necessary in the defense or settlement of such Third Party Claim. (c) The Sellers or the Buyer, as the case may be, shall, and shall cause each of its Affiliates and representatives to, reasonably cooperate with the Controlling Party in the defense of any Third Party Claim. The Indemnifying Party shall be authorized to consent to a settlement of, or the entry of any judgment arising from, any Third Party Claim, without the consent of any Indemnified Party; provided that (i) such settlement shall not encumber any of the assets of the Indemnified Party or contain any restriction or condition that would apply to such Indemnified Party or to the conduct of the Indemnified Party’s business, (ii) the Indemnifying Party shall pay all amounts arising out of such settlement or judgment concurrently with the effectiveness of such settlement (subject to Section 11.3, if applicable), and (iii) the Indemnifying Party shall obtain, as a condition of any settlement or other resolution, a complete release of any Indemnified Party potentially affected by such Third Party Claim.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.