Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.
Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs: (a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed; (b) The Court has entered an order granting Preliminary Approval of the Agreement; (c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and (d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable. 9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement. 9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint. 9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
