Tenant Estoppels (a) Each Seller shall prepare and deliver to each Tenant at such Seller’s Property an estoppel certificate in the form of Exhibit A attached hereto (the “Tenant Estoppel”) and request each such Tenant to execute and deliver the Tenant Estoppel to such Seller. Each Seller shall use commercially reasonable efforts to obtain the prompt return of the executed Tenant Estoppels in substantially the same form as Exhibit A attached hereto from each Tenant at such Seller’s Property prior to the Closing, without the obligation to make any payments or grant any concessions under the Leases. If a Tenant returns an executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease as defined below) to such Seller, such Seller shall promptly deliver to the Buyer, or make available on Seller’s transaction website, a copy of such executed Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable) following such Seller’s receipt of such Tenant Estoppel (or Lease Required Estoppel or Statement of Lease, if applicable).
Tenant Estoppel If a Tenant Estoppel is delivered by Sellers to Buyer, Buyer may nevertheless disapprove such Tenant Estoppel if and only if it does not contain such items as are required to be given in connection with an estoppel certificate pursuant to the Tenant’s Lease, or contains allegations of an uncured material default by a Seller or contains information that materially deviates from the facts and financial information contained in the Offering Memorandum, the Due Diligence Materials or in this Agreement. If Sellers are unable to obtain Tenant Estoppels from a sufficient number of Tenants to satisfy the ********** ******* (***) *********** set forth in this Section 7.2(b) on or before the Closing Date (or have not delivered Tenant Estoppels from the Required Tenants), then the Closing Date for any applicable Portfolio shall be adjourned for a period not to exceed thirty (30) days for Sellers to obtain the sufficient number of Tenant Estoppels (or Estoppel Certificates from the Required Tenants, as the case may be). In addition, if Sellers are unable to obtain Tenant Estoppels from a sufficient number of Tenants to satisfy the ********** ******* (***) *********** set forth in this Section 7.2(b) on or before the Closing Date (as may be extended hereunder), an individual Seller shall have the right to elect to execute and deliver to Buyer a certificate substantially in the form of Exhibit P attached hereto (each such certificate, a “Seller’s Estoppel”) with respect to such additional lease(s) at such individual Seller’s Building and selected by Seller as would satisfy the requirement; provided, however, that an individual Seller shall not have the right to deliver a Seller’s Estoppel in lieu of Tenant Estoppels from Required Tenants. In the event that an individual Seller elects to deliver such a Seller’s Estoppel, each statement therein made by such Seller shall constitute warranties and representations by such Seller hereunder which shall survive for a period terminating on the earlier of (i) December 28, 2006, or (ii) the date on which Buyer has received an executed Tenant Estoppel signed by the applicable Tenant under the Lease in question that is not inconsistent with Seller’s Estoppel. With respect to the rentable area of the Buildings leased to the GSA, each individual Seller shall, as applicable, use commercially reasonable efforts to obtain a supplemental lease agreement, novation agreement, statement of lease or similar instrument delivered by the GSA (a “GSA Estoppel”) for Leases to the GSA in excess of 10,000 rentable square feet (a “Material GSA Lease”); provided, however, the delivery of a GSA Estoppel shall not be a condition precedent to Buyer’s obligation to consummate the transaction contemplated hereunder; provided, further that Sellers shall execute and deliver to Buyer a certificate substantially in the form of Exhibit P attached hereto (each such certificate, a “Seller’s GSA Estoppel”) with respect to all Material GSA Leases at such individual Seller’s Building. In the event that an individual Seller elects to deliver such a Seller’s GSA Estoppel, each statement therein made by such Seller shall constitute warranties and representations by such Seller hereunder which shall survive for a period terminating on the earlier of (i) December 28, 2006, or (ii) the date on which Buyer has received an executed GSA Estoppel signed by the GSA under the Material GSA Lease in question.
Tenant Estoppel Certificate Please refer to the documents described in Schedule 1 hereto, (the “Lease Documents”) including the “Lease” therein described; all defined terms in this Certificate shall have the same meanings as set forth in the Lease unless otherwise expressly set forth herein. The undersigned Tenant hereby certifies that it is the tenant under the Lease. Tenant hereby further acknowledges that it has been advised that the Lease may be collaterally assigned in connection with a proposed financing secured by the Property and/or may be assigned in connection with a sale of the Property and certifies both to Landlord and to any and all prospective mortgagees and purchasers of the Property, including any trustee on behalf of any holders of notes or other similar instruments, any holders from time to time of such notes or other instruments, and their respective successors and assigns (the “Beneficiaries”) that as of the date hereof:
Tenant Estoppel Certificates (a) Seller agrees from and after receipt of the Assumption Approval as set forth in Section 9.1 and provided this Agreement is in full force and effect, within five (5) business days after being requested by Purchaser to do so, to deliver to all tenants of the Property a request for an estoppel certificate in the form of EXHIBIT D attached hereto, which form may be revised if so requested by the Existing Lender. The parties agree that, subject to the provisions of subparagraph (b) below, it shall be a condition to Purchaser's obligation to close under this Agreement that an estoppel certificate either substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, dated not earlier than ten (10) business days prior to the Closing Date, be delivered to Purchaser no later than five (5) business days before Closing from tenants under the Leases occupying, in the aggregate, not less than 75% of the rentable area of the Property, including all tenants occupying at least a full floor or more of space (a "TENANT ESTOPPEL"), Seller agrees to use good faith efforts to obtain such Tenant Estoppels, provided however, Seller shall not be obligated to pay tenants in order to do so. Notwithstanding the foregoing, if at Closing Seller delivers such Tenant Estoppels from tenants occupying at least 60% of the rentable area of the Property, Seller may execute and deliver to Purchaser, at Closing, its own certificate with respect to tenants occupying up to an additional 15% of the rentable area of the Property (substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, appropriately modified to reflect that they are certificates of Seller and made to Seller's knowledge; hereinafter, the "SELLER'S ESTOPPEL CERTIFICATE") and the statements of Seller contained therein shall survive the Closing until the earlier of (a) one hundred and eighty (180) days after Closing, or (b) the date Purchaser obtains an estoppel certificate from a tenant for whom Seller delivered a Seller's Estoppel Certificate.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.
TENANT'S ESTOPPEL CERTIFICATE From time to time, upon written request of Landlord, Tenant shall execute, acknowledge and deliver to Landlord or its designee, a written certificate stating (a) the date this Lease was executed, the Commencement Date of the Term and the date the Term expires; (b) the date Tenant entered into occupancy of the Premises; (c) the amount of Rent and the date to which such Rent has been paid; (d) that this Lease is in full force and effect and has not been assigned, modified, supplemented or amended in any way (or, if assigned, modified, supplemented or amended, specifying the date and terms of any agreement so affecting this Lease); (e) that this Lease represents the entire agreement between the parties with respect to Tenant’s right to use and occupy the Premises (or specifying such other agreements, if any); (f) that all obligations under this Lease to be performed by Landlord as of the date of such certificate have been satisfied (or specifying those as to which Tenant claims that Landlord has yet to perform); (g) that all required contributions by Landlord to Tenant on account of Tenant’s improvements have been received (or stating exceptions thereto); (h) that on such date there exist no defenses or offsets that Tenant has against the enforcement of this Lease by Landlord (or stating exceptions thereto); (i) that no Rent or other sum payable by Tenant hereunder has been paid more than one (1) month in advance (or stating exceptions thereto); (j) that a currently valid Letter of Credit has been deposited with Landlord, stating the original amount thereof and any increases or decreases thereto; and (k) any other matters evidencing the status of this Lease that may be required either by a lender making a loan to Landlord to be secured by a deed of trust covering the Building or the Project or by a purchaser of the Building or the Project. Any such certificate delivered pursuant to this Paragraph 30 may be relied upon by a prospective purchaser of Landlord’s interest or a mortgagee of Landlord’s interest or assignee of any mortgage upon Landlord’s interest in the Premises. If Tenant shall fail to provide such certificate within ten (10) days of receipt by Tenant of a written request by Landlord as herein provided, such failure shall, at Landlord’s election, constitute a Default under this Lease, and Tenant shall be deemed to have given such certificate as above provided without modification and shall be deemed to have admitted the accuracy of any information supplied by Landlord to a prospective purchaser or mortgagee.
Substitute Premises The “Substitute Premises” shall mean a parcel of land located by itself on a separate tax parcel with a completed building constructed thereon, with respect to which a certificate of occupancy has been issued and all other licenses and permits have been received, provided, however, that such land and building shall have a then-current appraised value at least equal to the current appraised value of the Premises (or in the case of damage or destruction the anticipated appraised value of the building) upon completion of the Building. Notwithstanding the immediately preceding sentence, the Substitute Premises shall not be required to be located in the same state as the Premises if Master Tenant pays to or for the benefit of Landlord all costs and expenses incurred by Landlord and Fee Mortgagee in connection with the acquisition and ownership of such property which would not have been incurred had the Substitute Premises been located in the same state as the Premises.
