DEFAULT ON DELIVERY If during the Contract period an Authorized User has issued a Purchase Order on or before Final Order Due Date for a Vehicle, and that Vehicle becomes unavailable or cannot be supplied for any reason (except as provided for in Appendix B §48 Savings/Force Majeure), following the issuance of the Purchase Order, a substitute Vehicle deemed by the Authorized User to be equal to the specifications for the Vehicle specified in the Mini-Bid, must be supplied by Contractor if requested by the Authorized User. If the Vehicle awarded in the Mini-Bid (i.e., Model Year, Make, Model, Model Code) is not available or not deemed equal to the specifications for the Vehicle specified in the Mini-Bid, then Contractor must supply a similar vehicle that meets the specifications for the Vehicle provided in the Mini-Bid. The price for substitute Vehicles shall be equal to or less than the Base NYS Vehicle Price for the Vehicle provided in the Mini-Bid. Alternatively, the Authorized User may, at their sole discretion, cancel the order and purchase the Vehicle from other sources. In such event the Contractor shall reimburse the Authorized User for all excess costs over the contract price.
Buyer’s Default Seller’s remedies shall be limited to liquidated damages in the amount of the Xxxxxxx Money set forth in Section IV. It is agreed that such payments and things of value are liquidated damages and are Seller’s sole and only remedy for Buyer’s failure to perform the obligations of this Agreement. The Parties agree that Seller’s actual damages in the event of Buyer’s default would be difficult to measure, and the amount of the liquidated damages herein provided for is a reasonable estimate of such damages.
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Lessor's Remedies on Default If Lessee defaults in the payment of rent or defaults in the performance of any of the other covenants or conditions hereof, Lessor may give Lessee notice of such default and if Lessee does not cure any such default within thirty (30) days after the giving of such notice (or if the default is of a nature that it cannot be completely cured within such period, if Lessee does not commence such cure within such thirty (30) days and thereafter proceed with reasonable diligence and in good faith to cure such default), then Lessor may terminate this Lease on not less than thirty (30) days' notice to Lessee. On the date specified in such notice, the term of this Lease shall terminate and Lessee shall then quit and surrender the Premises to Lessor, without extinguishing Lessee’s liability. If this Lease shall have been so terminated by Lessor, Lessor may at any time thereafter resume possession of the Premises by any lawful means and remove Lessee or other occupants and their effects.
Seller’s Default Buyer may elect to treat this Agreement as cancelled, in which case all Xxxxxxx Money paid by Buyer hereunder shall be returned and Buyer may recover such damages as may be proper, or Buyer may elect to treat this Agreement as being in full force and effect and Buyer shall have the right to specific performance or damages, or both.
Default of Purchasers If any Purchaser or Purchasers default in their obligations to purchase Offered Securities hereunder and the aggregate principal amount of Offered Securities that such defaulting Purchaser or Purchasers agreed but failed to purchase does not exceed 10% of the total principal amount of Offered Securities, CSFBC may make arrangements satisfactory to the Company for the purchase of such Offered Securities by other persons, including any of the Purchasers, but if no such arrangements are made by the Closing Date, the non-defaulting Purchasers shall be obligated severally, in proportion to their respective commitments hereunder, to purchase the Offered Securities that such defaulting Purchasers agreed but failed to purchase. If any Purchaser or Purchasers so default and the aggregate principal amount of Offered Securities with respect to which such default or defaults occur exceeds 10% of the total principal amount of Offered Securities and arrangements satisfactory to CSFBC and the Company for the purchase of such Offered Securities by other persons are not made within 36 hours after such default, this Agreement will terminate without liability on the part of any non-defaulting Purchaser or the Company, except as provided in Section 9. As used in this Agreement, the term "Purchaser" includes any person substituted for a Purchaser under this Section. Nothing herein will relieve a defaulting Purchaser from liability for its default.
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
Default Remedies Termination If the Stop Work Order is canceled, ODHS may, after receiving and evaluating a request by the Contractor, make an adjustment in the time required to complete this Contract and the Contract price by a duly executed amendment.
REMEDIES IN CASE OF AN EVENT OF DEFAULT If there shall have occurred and be continuing an Event of Default, then and in every such case, the Pledgee shall be entitled to exercise all of the rights, powers and remedies (whether vested in it by this Agreement, any other Secured Debt Agreement or by law) for the protection and enforcement of its rights in respect of the Collateral, and the Pledgee shall be entitled to exercise all the rights and remedies of a secured party under the Uniform Commercial Code as in effect in any relevant jurisdiction and also shall be entitled, without limitation, to exercise the following rights, which each Pledgor hereby agrees to be commercially reasonable:
(i) to receive all amounts payable in respect of the Collateral otherwise payable under Section 6 hereof to the Pledgors;
(ii) to transfer all or any part of the Collateral into the Pledgee’s name or the name of its nominee or nominees;
(iii) to vote all or any part of the Collateral (whether or not transferred into the name of the Pledgee) and give all consents, waivers and ratifications in respect of the Collateral and otherwise act with respect thereto as though it were the outright owner thereof (each Pledgor hereby irrevocably constituting and appointing the Pledgee the proxy and attorney-in-fact of such Pledgor, with full power of substitution to do so);
(iv) at any time and from time to time to sell, assign and deliver, or grant options to purchase, all or any part of the Collateral, or any interest therein, at any public or private sale, without demand of performance, advertisement or notice of intention to sell or of the time or place of sale or adjournment thereof or to redeem or otherwise (all of which are hereby waived by each Pledgor), for cash, on credit or for other property, for immediate or future delivery without any assumption of credit risk, and for such price or prices and on such terms as the Pledgee in its absolute discretion may determine, provided that at least 10 days’ written notice of the time and place of any such sale shall be given to the Pledgors. The Pledgee shall not be obligated to make any such sale of Collateral regardless of whether any such notice of sale has theretofore been given. Each Pledgor hereby waives and releases to the fullest extent permitted by law any right or equity of redemption with respect to the Collateral, whether before or after sale hereunder, and all rights, if any, of marshalling the Collateral and any other security for the Obligations or otherwise. At any such sale, unless prohibited by applicable law, the Pledgee on behalf of the Secured Creditors may bid for and purchase all or any part of the Collateral so sold free from any such right or equity of redemption. Neither the Pledgee nor any other Secured Creditor shall be liable for failure to collect or realize upon any or all of the Collateral or for any delay in so doing nor shall any of them be under any obligation to take any action whatsoever with regard thereto; and
(v) to set-off any and all Collateral against any and all Obligations.
Purchaser’s Default If Purchaser fails to consummate this transaction for any reason other than Seller’s intentional and willful default, failure of a condition to Purchaser’s obligation to close, or the exercise by Purchaser of an express right of termination granted herein, Seller shall be entitled, as its sole remedy hereunder, to terminate this Agreement and to receive and retain the Xxxxxxx Money as full liquidated damages for such default of Purchaser, the parties hereto acknowledging that it is impossible to estimate more precisely the damages which might be suffered by Seller upon Purchaser’s default, and that said Xxxxxxx Money is a reasonable estimate of Seller’s probable loss in the event of default by Purchaser. Seller’s retention of said Xxxxxxx Money is intended not as a penalty, but as full liquidated damages. The right to retain the Xxxxxxx Money as full liquidated damages is Seller’s sole and exclusive remedy in the event of default hereunder by Purchaser, and Seller hereby waives and releases any right to (and hereby covenants that it shall not) xxx the Purchaser: (a) for specific performance of this Agreement, or (b) to recover actual damages in excess of the Xxxxxxx Money. The foregoing liquidated damages provision shall not apply to or limit Purchaser’s liability for Purchaser’s obligations under Sections 3.1(b), 3.1(c), 3.7 and 10.1 of this Agreement. Purchaser hereby waives and releases any right to (and hereby covenants that it shall not) xxx Seller or seek or claim a refund of said Xxxxxxx Money (or any part thereof) on the grounds it is unreasonable in amount and exceeds Seller’s actual damages or that its retention by Seller constitutes a penalty and not agreed upon and reasonable liquidated damages.
