Common use of TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS Clause in Contracts

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. ‌ a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌

Appears in 6 contracts

Samples: Master Contract, Master Contract, Master Contract

AutoNDA by SimpleDocs

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. ‌ a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌.

Appears in 3 contracts

Samples: Master Contract, Master Contract, Master Contract

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌.

Appears in 3 contracts

Samples: Master Contract, Master Contract, Master Contract

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌

Appears in 1 contract

Samples: Master Contract

AutoNDA by SimpleDocs

TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. (a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. (b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. (c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌.

Appears in 1 contract

Samples: Master Contract

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!