ALTERATION OF AGREEMENT A. It is hereby agreed that any alteration or modification of this Agreement shall be binding upon the parties only if agreed to in writing by both parties.
B. The waiver of any condition of this Agreement by either party shall not constitute a precedent in the future enforcement of all terms and conditions herein.
Licenses for Permanent Installation The contractor must comply with all State mandatory licensing requirements prior to installation. Questions on licensing requirements should be directed to the State Licensing Board. Contractor must furnish and install all furniture and materials in compliance with all applicable codes, whether local, state, or federal; and that all permits or licenses required for installation will be obtained without cost to the State.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board.
(2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein.
(3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee
B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Section 8.1(a) is amended in its entirety to read as follows: Subject to the provisions of Sections 8.2, 10, and 15, Tenant shall, at Tenant's sole cost and expense and at all times, keep the Building Complex and every part thereof in good order, condition and repair (whether or not the need for such repairs occurs as a result of Tenant's use, any prior use, the elements or the age of such portion of the Building Complex), including, without limiting the generality of the foregoing, plumbing, electrical lighting facilities, boilers, fired or unfired pressure vessels, fire hose connections, fixtures, interior walls, exterior walls, roof, ceilings, floors, windows, doors, plate glass, and skylights, parking areas and lighting, driveways, sidewalks, landscaping, irrigation systems, and subject to Section 8.1(b) below, heating, air conditioning and ventilating systems, but excluding any items which are the responsibility of Landlord pursuant to Section 8.2 below. Tenant, in keeping the Building Complex in good order, condition and repair, shall exercise and perform good maintenance practices, including, without limitation, providing janitorial services to the Building Complex substantially equivalent to those attached hereto as Exhibit I and, snow, ice and trash removal service. Tenant's obligations shall include restorations, replacements or renewals when necessary to keep the Building Complex and all improvements thereon or a part thereof in good order, condition and state of repair.
(b) Section 8.1(b) is amended in its entirety to read as follows: Tenant shall procure and pay the cost of a contract for maintenance of the heating, air conditioning and ventilating systems for the Building Complex with a reputable contractor licensed in the State of Colorado and reasonably satisfactory to Landlord.
(c) Section 8.1(c) is amended to replace, in both places where it is used, the word "Premises" with the words "Building Complex" and to add the words "including, without limitation, the Premises," before the words "after twenty".
(d) Section 8.2 is amended in its entirety to read as follows:
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above.
(B) If the damage does not, in the opinion of a licensed third party arbitrator reasonably acceptable to Lessee and Lessor, render the Leased Premises unfit for occupancy, then Lessor agrees that the damage shall be repaired as soon as practicable and in that case, Lessee shall pay full rent during the repair period. All repairs shall be paid for by Lessee out of any insurance proceeds received (which Lessor shall cooperate to make available), but if the insurance proceeds are insufficient to rebuild or repair the Leased Premises according to the original plans and specifications, whether repair or restoration is commenced pursuant to paragraph A or B hereof, then Lessee agrees to pay all additional amounts that are required to rebuild the building in accordance with the original plans and specifications. All improvements or betterments placed by Lessee on the demised premises shall, however, in any event, be repaired and replaced by Lessee at its own expense and not at the expense of Lessor. The purpose of this Article is to require Lessee to carry insurance coverage on the Leased Premises sufficient to rebuild the improvements in the event of damage or destruction. Lessee shall be under no obligation to so rebuild during the last five (5) years of the term, as extended, as the case may be, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. Risk that the insurance company shall be insolvent or shall refuse to make insurance proceeds available shall be with Lessee. The Leased Premises shall be so restored or rebuilt so as to be of at least equal value and substantially the same character as prior to such damage or destruction. If the insurance proceeds are less than $100,000 they shall be paid to Lessee for such repair and restoration. If the insurance proceeds are greater than or equal to $100,000 they shall be deposited by Lessee and Lessor into a customary construction escrow at a nationally recognized title insurance company, or at Lessee's option, with Lessor ("Escrowee") and shall be made available from time to time to Lessee for such repair and restoration. Such proceeds shall be disbursed in conformity with the terms and conditions of a commercially reasonable construction loan agreement. Lessee shall, in either instance, deliver to Lessor or Escrowee (as the case may be) satisfactory evidence of the estimated cost of completion together with such architect's certificates, waivers of lien, contractor's sworn statements and other evidence of cost and of payments as the Lessor or Escrowee may reasonably require and approve. If the estimated cost of the work exceeds One Hundred Thousand Dollars ($100,000), all plans and specifications for such rebuilding or restoration shall be subject to the reasonable approval of Lessor.
(C) Lessee shall comply with the time period stated above for restoration of the Leased Premises as set forth in this Article; provided, however, that said period of time shall be extended for a period or periods of time equal to any period or periods of delay caused by strikes, lockouts, fire, or other casualty, the elements, acts of God, delay by or refusal or failure of governmental authorities to grant necessary permits and approvals for the reconstruction of the Leased Premises (Lessee agreeing to use reasonable diligence to procure the same), or other causes other than financial, beyond Lessee's reasonable control or the reasonable control of Lessee's contractor.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Utility Installations Trade Fixtures Alterations 8.3.1 The term “Utility Installations” refers to all floor and window coverings, air and/or vacuum lines, power panels, electrical distribution, security and fire protection systems, communication cabling, lighting fixtures, HVAC equipment, plumbing, and fencing in or on the Premises. The term “Trade Fixtures” shall mean Lessee’s machinery and equipment that can be removed without doing material damage to the Premises. The term “Alterations” shall mean any modification of the improvements, other than Utility Installations or Trade Fixtures, whether by addition or deletion. “Lessee Owned Alterations and/or Utility Installations” are defined as Alterations and/or Utility Installations made by Lessee that are not yet owned by Lessor pursuant to Section 8.4.1.
