Tenant Waiver TENANT SPECIFICALLY ACKNOWLEDGES THAT TENANT HAS VOLUNTARILY, KNOWINGLY AND INTELLIGENTLY WAIVED CERTAIN DUE PROCESS RIGHTS TO A PREJUDGMENT HEARING BY AGREEING TO THE TERMS OF THE FOREGOING PARAGRAPHS REGARDING CONFESSION OF JUDGMENT. TENANT FURTHER SPECIFICALLY AGREES THAT IN THE EVENT OF DEFAULT, LANDLORD MAY PURSUE MULTIPLE REMEDIES INCLUDING OBTAINING POSSESSION PURSUANT TO A JUDGMENT BY CONFESSION AND EXECUTING UPON SUCH JUDGMENT. IN SUCH EVENT AND SUBJECT TO THE TERMS SET FORTH HEREIN, LANDLORD SHALL PROVIDE FULL CREDIT TO TENANT FOR ANY MONTHLY CONSIDERATION WHICH LANDLORD RECEIVES FOR THE LEASED PREMISES IN MITIGATION OF ANY OBLIGATION OF TENANT TO LANDLORD FOR THAT MONEY. FURTHERMORE, TENANT SPECIFICALLY WAIVES ANY CLAIM AGAINST LANDLORD AND LANDLORD’S COUNSEL FOR VIOLATION OF TENANT’S CONSTITUTIONAL RIGHTS IN THE EVENT THAT JUDGMENT IS CONFESSED PURSUANT TO THIS LEASE.
Leasehold Mortgage Lessee shall at all times and from time to time have the right to encumber by mortgage, deed of trust, or security agreement (the “Mortgage”) Lessee’s leasehold estate in the Premises, together with Lessee’s rights and interests in all buildings, fixtures, equipment, and improvements situated thereon, and all rents, issues, profits, revenues, and other income to be derived by Lessee therefrom, to secure such loans from time to time made by any Person to Lessee; provided, however, that such Mortgage shall in no event encumber Lessor’s fee title or leasehold interest (as applicable) in the Premises or Lessor’s interest under this Lease.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Lease Agreements 11 Section 3.15
Surrender of Demised Premises Upon the expiration or earlier termination of this Lease with respect to all or any portion of any Demised Premises, whether on the Expiration Date with respect to the entire Demised Premises, on any Property Termination Date with respect any individual Demised Premises or otherwise, Tenant shall surrender and deliver the applicable Demised Premises to Landlord (a) vacant and free from all subtenants, licensees or other occupants (other than pursuant to subleases for which Landlord has granted a Subtenant SNDA), (b) in at least the same condition as the condition of such Demised Premises on the Commencement Date, ordinary wear and tear excepted and except as repaired, restored, altered or added to as permitted or required by the provisions of this Lease, (c) in compliance in all material respects with all applicable Property Requirements, (d) with all Tenant’s Property and all Alterations (other than Permissible Alterations that Tenant elects not to remove) removed, and with such Demised Premises repaired and restored in accordance with the terms hereof following any such removal and (e) free and clear of all Encumbrances first arising after the Commencement Date, other than Permitted Encumbrances (except for any Excepted Liens not Bonded by Tenant, Tenant hereby acknowledges that Tenant shall in all events remain liable for the discharging or Bonding of all Excepted Liens in accordance with the terms of this Lease) (the foregoing, collectively, the “Required Return Condition”). Notwithstanding the foregoing, solely to the extent that any such termination of this Lease results from a Casualty or a Condemnation, the foregoing clauses (b), (c) and (d) shall not apply to the portion of the applicable Demised Premises affected by such Casualty or Condemnation and Tenant’s obligations with respect thereto shall instead be as provided in Article XII.
Surrender of Leased Premises Upon any termination of this Lease, whether by lapse of time, cancellation pursuant to an election provided for herein, forfeiture, or otherwise, Tenant shall immediately surrender possession of the Leased Premises and all buildings and improvements on the same to Landlord in good and tenantable repair, reasonable wear and damage from fire or other casualty or peril excepted, and shall surrender all keys for the Leased Premises to Landlord at the place then fixed for the payment of rent and shall inform Landlord of all combinations of locks, safes and vaults, if any, in the Leased Premises. At any time during the ten (10) days before the termination date of this Lease, Tenant, if not in default hereunder at such time, shall have the right to remove, and at the end of the term, if directed to do so by Landlord, shall remove from the Leased Premises all furniture, furnishings, signs, and equipment then installed or in place in, on or about the Leased Premises; provided, however, Tenant shall, and it covenants and agrees to, make all repairs to the Leased Premises required because of such removal. If any of such property shall remain on the Leased Premises after the end of the term hereof, such property shall be and become the property of Landlord without any claim therein of Tenant. Landlord may direct Tenant to remove such property, in which case Tenant Upon termination of this Lease, Tenant shall peaceably surrender the Leased Premises, including all fixtures and tenant improvements, in a neat and broom clean condition, and Tenant shall repair any holes or openings made by Tenant in the walls, roof or floor of the building, remove any protuberance and perform any maintenance or repairs required of Tenant by this Lease. If directed to do so by Landlord, Tenant shall also remove any improvements, additions or alterations made to the Leased Premises by Tenant even though such improvements by the terms of this Lease become a part of the Leased Premises.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Landlord Agreements Each Credit Party shall use commercially reasonable efforts to obtain a landlord agreement or bailee or mortgagee waivers, as applicable, from the lessor of each leased property, bailee in possession of any Collateral or mortgagee of any owned property with respect to each location where any Collateral is stored or located, which agreement shall be reasonably satisfactory in form and substance to Agent.
Leasehold Mortgages In connection with the Redevelopment of the Property, Tenant may from time to time grant one or more mortgages, deeds of trust or other security interests in its leasehold estate under this Lease (a “Leasehold Mortgage”) and assign this Lease as security for such Leasehold Mortgage(s). Such Leasehold Mortgages and any foreclosure, sale or other realization proceeding pursuant to any Leasehold Mortgage granted by Tenant and any deed or assignment in lieu thereof (“Realization Proceedings”) shall not require the consent of Landlord and shall not be subject to the provisions of Section 13 hereof. No Leasehold Mortgage shall place or create any lien or encumbrance affecting Landlord’s interest in the Property or the Improvements. The holder of any Leasehold Mortgage (a “Leasehold Mortgagee”) hereunder shall provide Landlord with notice of such Leasehold Mortgage together with a true copy of such Leasehold Mortgage and the name and address of such Leasehold Mortgagee (“Leasehold Mortgagee Address”). Following receipt of such notice by Landlord, the provisions of this Section 14 shall apply in respect to such Leasehold Mortgage. Tenant shall promptly provide to Landlord copies of the note and other instruments secured by any Leasehold Mortgage and any and all amendments to any such instruments as may be made from time to time.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
