Tenant Waiver definition

Tenant Waiver means the waiver by any Property Tenant of rights under the applicable Property Lease (including rights of first offer or refusal) arising as a result of the transactions contemplated by this Agreement and the Transaction Documents, which waiver is required to be obtained pursuant to the terms of the applicable Property Lease in order for such Property Lease to remain in full force and effect from and after the applicable Closing.
Sample 1Sample 2Sample 3
Tenant Waiver has the meaning given to it in the Tenant Waiver Protocol;
Sample 1Sample 2Sample 3

Examples of Tenant Waiver in a sentence

  • Additionally, the occurrence of an Access Refusal Event, Rehousing Refusal Event, and Tenant Waiver Event cannot prevent the Contractor from obtaining a Certificate of Availability and uplift in the Unitary Charge by the end of the Works Period.

  • Representation(a) An individual appellant may represent his or her interests before the Board; a cor- poration may be represented by one of its of- ficers; and a partnership or joint venture by one of its members; or any of these by an at- torney at law duly licensed in any state, Defense Acquisition Regulations System, DoD Ch. 2, App.

  • Subject to a Tenant Waiver, a Tenant's existing kitchen 'white goods' will be accommodated as part of the Refurbishment Works, where the existing dimensions of the kitchen allow for the new kitchen to be installed to meet the Availability Standards and placement of the white goods.

  • Additionally, the occurrence of an Access Refusal Event, Rehousing Refusal Event and Tenant Waiver Event cannot prevent the Contractor from obtaining a Certificate of Availability and uplift in the Unitary Charge by the end of the Works Period.

  • Subject to a Tenant Waiver and in accordance with Notes 27 and 28, the Contractor shall ensure during the carrying out of the Refurbishment Works;• any modifications and/or alterations to kitchens, bathrooms and W.Cs accommodate Tenants' own kitchens, bathrooms and W.Cs;• 90% of Dwellings receive each of the following:o new kitchenso new bathrooms ando new W.Cs; and• 100% of Dwellings receive new heating systems during the Refurbishment Works Programme.

  • Retention of existing heating systems by Tenants pursuant to a Tenant Waiver will be excluded from this calculation.

Related to Tenant Waiver

  • Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Landlord Agreement means an agreement substantially in the form provided by Lender to Borrower or such other form as Lender may agree to accept.

  • Tenant Lease means any lease entered into by the Borrower, any Loan Party or any Subsidiary with respect to any portion of a Property.

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord Consent and Estoppel means, with respect to any Leasehold Property, a letter, certificate or other instrument in writing from the lessor under the related lease, pursuant to which, among other things, the landlord consents to the granting of a Mortgage on such Leasehold Property by the Credit Party tenant, such Landlord Consent and Estoppel to be in form and substance acceptable to Collateral Agent in its reasonable discretion, but in any event sufficient for Collateral Agent to obtain a Title Policy with respect to such Mortgage.

  • Landlord Consent means a Landlord Consent substantially in the form of Exhibit G.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Space Lease The space or occupancy lease pursuant to which any Borrower holds a leasehold interest in the related Mortgaged Property, together with any estoppels or other agreements executed and delivered by the lessor in favor of the lender under the related Mortgage Loan(s).

  • Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition, Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 32 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Tenant Improvements Defined in Exhibit B, if any.

  • Subtenant means any Person entitled to occupy, use, or possess any Premises under a Sublease.

  • Premises Building Partial Damage shall herein mean damage or destruction to the building of which the Premises are a part to the extent that the cost of repair is less than 50% of the then replacement cost of such building as a whole.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • Landlord Access Agreement means a Landlord Access Agreement, substantially in the form of Exhibit G, or such other form as may reasonably be acceptable to the Administrative Agent.

  • Landlord shall have the meaning given such term in the preambles to this Agreement and shall also include their respective permitted successors and assigns.

  • Tenants means the tenants under the Leases.

  • Sublease means a lease of goods the right to possession and use of which was acquired by the lessor as a lessee under an existing lease.

  • Habitable space means space in a building used for living, sleeping, eating, or cooking. Habitable space does not include a heater or utility room, a crawl space, a basement, an attic, a garage, an open porch, a balcony, a terrace, a court, a deck, a bathroom, a toilet room, a closet, a hallway, a storage space, and other similar spaces not used for living, sleeping, eating, or cooking.

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and