Common use of Tenant Work Clause in Contracts

Tenant Work. Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval (which shall not be unreasonably withheld, conditioned or delayed) of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner, with good construction practices, using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; (iii) in a manner that does not impair any Landlord System or the structure or roof of the Building, and (iv) to the extent reasonably practicable, in a manner that minimizes any noise, vibration, particulates, dust infiltration or other disturbances that would unreasonably disturb owners or occupants of other parcels in the Project. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3.

Tenant Work. Before commencing beginning any repair or Alteration or any work affecting Lines (defined in Section 23) (collectively, “Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval (which shall not be unreasonably withheld, conditioned or delayed) of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner, with good construction practices, manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair any Landlord System or the structure or roof of the Base Building, and (iv) to the extent reasonably practicable, in a manner that minimizes any noise, vibration, particulates, dust infiltration or other disturbances that would unreasonably disturb owners or occupants of other parcels in the Project. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

Tenant Work. Before commencing beginning any repair or Alteration or any work affecting Lines (collectively, “Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval (which shall not be unreasonably withheld, conditioned or delayed) of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insuranceinsurance in amounts and coverages as Landlord may reasonably require; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner, with good construction practices, manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair any Landlord System or the structure or roof of the Base Building, and (iv) to the extent reasonably practicable, in a manner that minimizes any noise, vibration, particulates, dust infiltration or other disturbances that would unreasonably disturb owners or occupants of other parcels in the Project. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of TenantTxxxxx’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

Tenant Work. Before commencing any repair or Alteration or any work affecting Lines (“Tenant Work”), other than any Tenant Work consisting of a repair that does not affect vertical Lines and is reasonably estimated to cost less than $50,000.00. Tenant shall deliver to Landlord, and obtain Landlord’s approval (which shall not be unreasonably withheld, conditioned or delayed) of, (a) names a)names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work work (i) in a good and workmanlike manner, with good construction practices, manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair any Landlord System or the structure or roof of the Base Building, and (iv) to the extent reasonably practicable, in a manner that minimizes any noise, vibration, particulates, dust infiltration or other disturbances that would unreasonably disturb owners or occupants of other parcels in the Project. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any ay notice, or cause such Tenant Work to be performed in any particular manner, . Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.