MAI Appraiser The cost of such application to the presiding judge shall be equally shared by the parties. Within five (5) days after completion of the third (3rd) MAI Appraiser’s appraisal, all three (3) MAI Appraisers shall meet and a majority of the MAI Appraisers shall attempt to determine the fair market value of the Premises or applicable portion thereof. If a majority are unable to determine the fair market value at such meeting, the three (3) appraisals shall be added together and their total divided by three (3). The resulting quotient shall be the Fair Market Value. If, however, either or both of the low appraisal or the high appraisal are more than ten percent (10%) lower or higher than the middle appraisal, any such lower or higher appraisal shall be disregarded. If only one (1) appraisal is disregarded, the remaining two (2) appraisals shall be added together and their total divided by two (2), and the resulting quotient shall be such Fair Market Value. If both the lower appraisal and higher appraisal are disregarded as provided herein, the middle appraisal shall be such Fair Market Value. In any event, the result of the foregoing appraisal process shall be final and binding.
Fair Market Rent In the event that it becomes necessary to determine the Fair Market Rent of any Facility for any purpose of this Master Lease, and the parties cannot agree among themselves on such Fair Market Rent within twenty (20) days after the first request made by one of the parties to do so, then either party may notify the other of a person selected to act as appraiser (such person, and each other person selected as provided herein, an “Appraiser”) on its behalf. Within fifteen (15) days after receipt of any such Notice, the other party shall by notice to the first party appoint a second person as Appraiser on its behalf. The Appraisers thus appointed, each of whom must be a member of The Appraisal Institute/American Institute of Real Estate Appraisers (or any successor organization thereto, or, if no such organization exists, a similarly nationally recognized real estate appraisal organization) with at least ten (10) years of experience appraising properties similar to the Facilities, shall, within forty-five (45) days after the date of the notice appointing the first appraiser, proceed to appraise the applicable Facility to determine the Fair Market Rent thereof as of the relevant date; provided, that if one Appraiser shall have been so appointed, or if two Appraisers shall have been so appointed but only one such Appraiser shall have made such determination within fifty (50) days after the making of the initial appointment, then the determination of such Appraiser shall be final and binding upon the parties. If two (2) Appraisers shall have been appointed and shall have made their determinations within the respective requisite periods set forth above and if the difference between the amounts so determined shall not exceed ten percent (10%) of the lesser of such amounts, then the Fair Market Rent shall be an amount equal to fifty percent (50%) of the sum of the amounts so determined. If the difference between the amounts so determined shall exceed ten percent (10%) of the lesser of such amounts, either party may request the appointment of Experts pursuant to Article XXXIV.
Independent Appraiser A Person with no material current or prior business or personal relationship with the Advisor or the Directors and who is a qualified appraiser of Real Property of the type held by the Company or of other Assets as determined by the Board. Membership in a nationally recognized appraisal society such as the American Institute of Real Estate Appraisers or the Society of Real Estate Appraisers shall be conclusive evidence of such qualification as to Real Property.
Rental Value Lessor shall also obtain and keep in force during the term of this Lease a policy or policies in the name of Lessor, with loss payable to Lessor and any Lender(s), insuring the loss of the full rental and other charges payable by all lessees of the Building to Lessor for one year (including all Real Property Taxes, insurance costs, all Common Area Operating Expenses and any scheduled rental increases). Said insurance may provide that in the event the Lease is terminated by reason of an insured loss, the period of indemnity for such coverage shall be extended beyond the date of the completion of repairs or replacement of the Premises, to provide for one full year's loss of rental revenues from the date of any such loss. Said insurance shall contain an agreed valuation provision in lieu of any co-insurance clause, and the amount of coverage shall be adjusted annually to reflect the projected rental income, Real Property Taxes, insurance premium costs and other expenses, if any, otherwise payable, for the next 12-month period. Common Area Operating Expenses shall include any deductible amount in the event of such loss.
Expert Determination 41.5.1 For a Dispute on any decision referred to an expert the Parties hereby agree that such decision shall be conducted expeditiously by an expert selected unanimously by the Parties to the Dispute. The expert is not an arbitrator and shall not be deemed to be acting in an arbitral capacity. The independent expert shall have an established reputation in the international petroleum industry as an expert on the matter in dispute and shall not at the time of the Dispute be engaged by any Party for work other than as the expert. The Party desiring an expert determination shall give the other Party written notice of the request for such determination. If the Parties to the Dispute are unable to agree upon an expert within twenty (20) Days after receipt of the notice of request for an expert determination, then, upon the request of any of the parties to the Dispute, the International Centre for Expertise of the International Chamber of Commerce (ICC) shall appoint such expert and shall administer such expert determination through the ICC’s Rules for Expertise. The expert, once appointed, shall have no ex parte communications with any of the parties to the Dispute concerning the expert determination or the underlying Dispute. Any hearing with an expert determination shall take place in The Hague, the Netherlands, unless the parties agree otherwise. All Parties agree to cooperate fully in the expeditious conduct of such expert determination and to provide the expert with access to all facilities, books, records, documents, information and personnel necessary to make a fully informed decision in an expeditious manner. Each Party shall prepare and exchange a written position paper setting 106 out its positions with respect to the Dispute. Each Party shall also prepare and exchange a written response to the other Party’s position paper. The position papers and responses may be accompanied by data and information in the submitting Party’s discretion. Before issuing his final decision, the expert shall issue a draft report and allow the Parties to the Dispute ten (10) Days to comment on it. The expert shall endeavor to resolve the Dispute within sixty (60) Days (but no later than ninety (90) Days) after receipt of each Party’s written response to the other Parties’ position paper taking into account the circumstances requiring an expeditious resolution of the matter in dispute. The expert’s decision shall be final and binding on the Parties to the Dispute unless challenged in an arbitration pursuant to Sub-Article 41.2 within sixty (60) Days of the date the expert’s final decision is received by the Parties to the Dispute and until replaced by such subsequent arbitral award. In such arbitration (i) the expert determination on the specific matter shall be entitled to a rebuttable presumption of correctness; and (ii) the expert shall not (without the written consent of the parties to the Dispute) be appointed to act as an arbitrator or as adviser to the Parties to the Dispute. 107
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Determination of Market Rent If Tenant timely and appropriately objects to the Market Rent in Tenant’s Acceptance, Landlord and Tenant shall attempt to agree upon the Market Rent using their best good-faith efforts. If Landlord and Tenant fail to reach agreement within twenty-one (21) days following Tenant’s Acceptance (“Outside Agreement Date”), then each party shall make a separate determination of the Market Rent which shall be submitted to each other and to arbitration in accordance with the following items (i) through (vii):
Appraiser If it becomes necessary to determine the Fair Market Value of the Premises for any purpose of this Lease, the same shall be determined by an independent appraisal firm, in which one or more of the members, officers or principals of such firm are Members of the Appraisal Institute (or any successor organization thereto) and who are expert in valuation of facilities used for the Primary Intended Use, as may be reasonably selected by Landlord and approved by Tenant (the “Appraiser”). Landlord shall cause such Appraiser to determine the Fair Market Value of the Premises as of the relevant date (giving effect to the impact, if any, of inflation from the date of the Appraiser’s decision to the relevant date) and the determination of such Appraiser shall be final and binding upon the parties. A written report of such Appraiser shall be delivered and addressed to each of Landlord and Tenant. To the extent consistent with sound appraisal practice as then existing at the time of any such appraisal, an appraisal of Fair Market Value for purposes of this Lease shall take into account and shall give appropriate consideration to all three customary methods of appraisal (i.e., the cost approach, the sales comparison approach and the income approach), and no one method or approach shall be deemed conclusive simply by reason of the nature of Landlord’s business or because such approach may have been used for purposes of determining the fair market value of the Premises at the time of acquisition thereof by Landlord. This provision for determination by appraisal shall be specifically enforceable to the extent such remedy is available under applicable law, and any determination hereunder shall be final and binding upon the parties except as otherwise provided by applicable law. Tenant shall pay the fees and expenses of the Appraiser and all other costs and expenses incurred in connection with such appraisal. If Landlord and Tenant are unable to agree upon the Appraiser within fifteen (15) days after Landlord notifies Tenant of the identity of Landlord’s selected Appraiser, then the following shall apply:
Architect 4.1.1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "
