Tenant’s Covenants The Tenant hereby covenants with the Landlord as follows:
Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.
LANDLORD'S COVENANTS The Landlord hereby covenants with the Tenant as follows:
Landlord’s Covenant Upon payment by the Tenant of the rents and other charges herein provided, and upon the observance and performance of all the covenants, terms and conditions on Tenant’s part to be observed and performed, Tenant shall peaceably and quietly hold and enjoy the Premises for the term hereby demised without hindrance or interruption by Landlord or any other person or persons lawfully or equitably claiming by, through or under the Landlord, subject, nevertheless, to the terms and conditions of this Lease.
TENANT'S INDEMNIFICATION OF LANDLORD Tenant shall indemnify, ------------------------------------ protect, defend and hold Landlord and Landlord's authorized representatives harmless from and against Claims arising from (a) the acts or omissions of Tenant or Tenant's Representatives or Visitors in or about the Property, or (b) any construction or other work undertaken by Tenant on the Premises (including any design defects), or (c) any breach or default under this Lease by Tenant, or (d) any loss, injury or damage, howsoever and by whomsoever caused, to any person or property, occurring in or about the Premises during the Term, excepting only Claims described in this clause (d) to the extent they are caused by the willful misconduct or negligent acts or omissions of Landlord or its authorized representatives.
LESSEE'S COVENANTS The Lessee agrees, warrants and represents that it shall commit no waste to the Demised Premises, nor suffer the same to be committed thereon, nor injure nor misuse the same; and further agrees, warrants and represents that the Lessee has neither the right nor the power to assign or hypothecate this Lease in any way whatsoever, except as otherwise provided in this Lease, or to make alterations or improvements to the demised premises, except non structural alterations in connection with the renovation of the demised premises for the permitted uses subject to the prior written approval of the Director of Operations , nor use the same for any purposes except as those expressly authorized herein or in accordance with the applicable provision of this Lease. The Lessee shall keep the premises in good condition, free of debris, safely and adequately for the uses and purposes hereby authorized. The Lessee shall deliver the premises up to Lessor upon the expiration or earlier termination of this Lease in reasonably good condition, normal wear and tear excepted, and the Lessee shall have no right nor obligation to remove any improvements to the Premises without the prior written consent of Lessor. Likewise, any fixtures, equipment, furnishings, supplies or inventory which are purchased or obtained, during the term of this Lease, by or for the Lessee utilizing any City operating or other revenue funds, including but not limited to state and federal funds administered by the City, shall become the property of Lessor upon the expiration or sooner termination of this Lease in good condition, normal wear and tear excepted, at the option of Lessor.
COVENANTS OF LANDLORD 22.1 Landlord represents and covenants that it has the right to make this Lease for the term aforesaid, and Landlord covenants that Tenant shall, during the term hereby created, freely, peaceably and quietly occupy and enjoy the full possession of the Premises without disturbance, molestation or hindrance by any person or entity whatever claiming an interest in the Premises prior or superior to Tenant's. Nothing in this Section 22.1, however, shall prevent Landlord from exercising any remedy available to it on account of an Event of Default by Tenant under this Lease. Landlord and Tenant each acknowledge and agree that Tenant's leasehold estate in and to the Premises vests on the date this Lease is fully executed by Landlord and Tenant, notwithstanding that the Lease Term will not commence until a future date. 22.2 Landlord hereby reserves to itself and its successors and assigns the following rights (all of which are hereby consented to by Tenant): (i) if imposed by Legal Requirements in Landlord's reasonable judgment after consultation with Tenant, if Tenant and/or its Affiliates are the lessees of more than fifty-one percent (51%) of the Premises, to change the street address and/or the arrangement and/or location of entrances, passageways, doors, doorways, corridors, elevators, stairs, toilets, or other public parts of the Building; and (ii) subject to compliance with Landlord's obligations pursuant to Sections 8.1 and 11.1, if imposed by Legal Requirements or if necessary for the proper functioning of the Premises after consultation with Tenant, if Tenant and/or its Affiliates are the lessees of more than fifty-one percent (51%) of the Premises, to erect, use and maintain pipes and conduits in and through the Premises; and (iii) to establish and maintain field offices in the Building for site engineers, property management and maintenance personnel comprising, in the aggregate, approximately 600 rentable square feet; and in number and locations that are typical for Class A suburban office buildings in the Market Area provided that, subject to the foregoing standards, Tenant shall have approval rights over the particular size and locations of such facilities, which approval shall not be unreasonably withheld, conditioned or delayed. Provided Landlord acts reasonably and diligently and in a manner not likely to materially, adversely affect Tenant's continuing and reasonably uninterrupted business functions, Landlord may exercise any or all of the foregoing rights without being deemed to be guilty of an eviction, actual or constructive, or a disturbance or interruption of the business of Tenant or of Tenant's use or occupancy of the Premises and without diminishing the rent payable hereunder.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Indemnity by Tenant To the extent permitted by Law, Tenant hereby indemnifies, and agrees to protect, defend and hold the Indemnitees harmless, against any and all actions, claims, demands, liability, costs and expenses, including attorneys’ fees and expenses for the defense thereof, arising from Tenant’s occupancy of the Premises, from the undertaking of any Tenant Additions or repairs to the Premises, from the conduct of Tenant’s business on the Premises, or from any breach or default on the part of Tenant in the performance of any covenant or agreement on the part of Tenant to be performed pursuant to the terms of this Lease, or from any willful act or negligence of Tenant, its agents, contractors, servants, employees, customers or invitees, in or about the Premises or the Property or any part of either. In case of any action or proceeding brought against the Indemnitees by reason of any such claim, upon notice from Landlord, Tenant covenants to defend such action or proceeding by counsel chosen by Landlord, in Landlord’s sole discretion. Landlord reserves the right to settle, compromise or dispose of any and all actions, claims and demands related to the foregoing indemnity. The foregoing indemnity shall not operate to relieve Indemnitees of liability to the extent such liability is caused by the willful and wrongful act of Indemnitees. Further, the foregoing indemnity is subject to and shall not diminish any waivers in effect in accordance with Section 16.04 by Landlord or its insurers to the extent of amounts, if any, paid to Landlord under its “All-Risks” property insurance.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
