Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
TENANT'S IMPROVEMENTS If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:
TENANT MAINTENANCE Tenant shall, at its sole cost and expense, keep and maintain the Premises (including appurtenances) and every part thereof in a good standard of maintenance and repair, or replacement, and in good and sanitary condition and repair. Tenant’s maintenance, repair and replacement responsibilities herein referred to include, but are not limited to, janitorization, all windows (interior and exterior), window frames, plate glass and glazing (destroyed by accident or act of third parties), truck doors, plumbing systems (such as water and drain lines, sinks, toilets, faucets, drains, showers and water fountains), electrical systems (such as panels, conduits, outlets, lighting fixtures, lamps, bulbs, tubes and ballasts), heating and air conditioning systems (such as compressors, fans, air handlers, ducts, mixing boxes, thermostats, time clocks, boilers, heaters, supply and return grills), structural elements and exterior surfaces of the Building, store fronts, roofs, downspouts, all interior improvements within the Premises including but not limited to wall coverings, window coverings, carpet, floor coverings, partitioning, ceilings, doors (both interior and exterior), including closing mechanisms, latches and locks, skylights (if any), automatic fire extinguishing systems, and elevators and all other interior improvements of any nature whatsoever, and all exterior improvements including but not limited to landscaping, sidewalks, driveways, parking lots including striping and sealing, sprinkler systems, lighting, ponds, fountains, waterways, and drains. Tenant shall be required to have the HVAC system serviced by a licensed HVAC contractor (approved by Landlord) at the earlier frequency of (a) the periodic servicing recommended by the manufacturer of such equipment in its written maintenance specifications or (b) semiannually throughout the Term of the Lease, and shall submit to Landlord copies of all related service reports within thirty (30) days of receipt and any repairs reports if requested by Landlord. Furthermore, Tenant shall inform Landlord in writing of the periodic service recommendations by the respective manufacturer within thirty (30) days of Tenant’s receipt of such information. Areas of excessive wear shall be replaced at Tenant’s sole expense upon Lease termination. Tenant hereby waives all rights under, and benefits of, Subsection 1 of Section 1932 and Section 1941 and 1942 of the California Civil Code and under any similar law, statute or ordinance now or hereafter in effect. Tenant understands and acknowledges that this Lease shall be deemed and construed to be a “triple net lease” and during the Initial Term, and any Extended Term(s), of this Lease Tenant shall pay Landlord, the Rent and other payments due hereunder, free of any charges, assessments, impositions, expenses or deductions of any kind and without abatement, deduction or setoff unless otherwise expressly provided in this Lease, and Landlord shall not be expected or required as a result of the relationship between Landlord and Tenant created by this Lease, to be obligated to make any payment to or on behalf of Tenant or be under any other obligation to Tenant hereunder except to the extent specifically provided in this Lease, and Tenant agrees to pay all costs and expenses of every kind which may arise or become due from Tenant under the provisions of this Lease during the Initial Term and any Extended Term(s). Except as expressly provided in this Lease or the Construction Agreement, Landlord shall not be liable and/or responsible under the provisions of this Lease for contributing any money for any maintenance, repairs and/or replacement of the Premises or any part thereof and as to the maintenance, repairs or replacement obligations of Tenant under this Lease, Tenant waives any and all rights it might otherwise have to assert that such expenditure is more appropriately a Landlord expenditure which should be treated as a capital expenditure and/or to be amortized as an item of Additional Rent hereunder. For example, if during the Lease Term (including any Extended Term(s)), a portion or the entire roof membrane and/or HVAC system needs to be repaired or replaced, such expenditure shall not be treated as a capital expenditure to be borne by Landlord, but rather Tenant shall be responsible, upon such occurrence, for bearing the entire cost for such repair and/or replacement. By placing their initials below, both parties acknowledge their understanding and their agreement with the provisions of this Paragraph 8. Initials: DWD Initials: JA Tenant Landlord
Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.
