Parties in Possession Except as disclosed on Exhibit B, there are no parties in possession of any Leased Property or any portion thereof as managers, lessees, tenants at sufferance, or trespassers.
Quiet Possession Subject to payment by Lessee of the Rent and performance of all of the covenants, conditions and provisions on Lessee's part to be observed and performed under this Lease, Lessee shall have quiet possession and quiet enjoyment of the Premises during the term hereof.
DELAY IN POSSESSION If for any reason Lessor cannot deliver possession of the Premises to Lessee by the Early Possession Date, if one is specified in Paragraph 1.4, or if no Early Possession Date is specified, by the Commencement Date, Lessor shall not be subject to any liability therefor, nor shall such failure affect the validity of this Lease, or the obligations of Lessee hereunder, or extend the term hereof, but in such case, Lessee shall not, except as otherwise provided herein, be obligated to pay rent or perform any other obligation of Lessee under the terms of this Lease until Lessor delivers possession of the Premises to Lessee. If possession of the Premises is not delivered to Lessee within sixty (60) days after the Commencement Date, Lessee may, at its option, by notice in writing to Lessor within ten (10) days after the end of said sixty (60) day period, cancel this Lease, in which event the parties shall be discharged from all obligations hereunder; provided further, however, that if such written notice of Lessee is not received by Lessor within said ten (10) day period, Lessee's right to cancel this Lease hereunder shall terminate and be of no further force or effect. Except as may be otherwise provided, and regardless of when the Original Term actually commences, if possession is not tendered to Lessee when required by this Lease and Lessee does not terminate this Lease, as aforesaid, the period free of the obligation to pay Base Rent, if any, that Lessee would otherwise have enjoyed shall run from the date of delivery of possession and continue for a period equal to the period during which the Lessee would have otherwise enjoyed under the terms hereof, but minus any days of delay caused by the acts, changes or omissions of Lessee.
TERM; POSSESSION The term of this Lease (the “Term”) shall commence on the Commencement Date as described below and, unless sooner terminated, shall expire on the Expiration Date set forth in the Basic Lease Information (the “Expiration Date”). The “Commencement Date” shall be the earlier of (a) the date on which Landlord tenders possession of the Premises to Tenant, with all of Landlord’s construction obligations, if any, “Substantially Completed” as provided in the Construction Rider attached as Exhibit B (the “Construction Rider”) or, in the event of any “Tenant Delay,” as defined in the Construction Rider, the date on which Landlord could have done so had there been no such Tenant Delay; or (b) the date upon which Tenant, with Landlord’s written permission, actually occupies and conducts business in any portion of the Premises. The parties anticipate that the Commencement Date will occur on or about the Scheduled Commencement Date set forth in the Basic Lease Information (the “Scheduled Commencement Date”). Landlord shall pay Tenant’s hold-over charges if the Premises are not Substantially Completed within seventy-five (75) days after Lease execution, provided, however, that Landlord shall not be liable for any other claims, damages or liabilities if the Premises are not ready for occupancy by the Scheduled Commencement Date. When the Commencement Date has been established, Landlord and Tenant shall at the request of either party confirm the Commencement Date and Expiration Date in writing.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
Damage to Leased Premises 14 10.1 Landlord's Duty To Restore................................... ..........14 10.2 Insurance Proceeds......................................................14 10.3 Landlord's Right To Terminate ..........................................14 10.4 Tenant's Right To Terminate.............................................15 10.5 Tenant's Waiver.........................................................15
Landlords and Tenants Property All fixtures, machinery, equipment, improvements and appurtenances attached to, or built into, the Premises at the commencement of, or during the Term, whether or not placed there by or at the expense of Tenant, shall become and remain a part of the Premises; shall be deemed the property of Landlord (the “Landlord’s Property”), without compensation or credit to Tenant; and shall not be removed by Tenant at the Expiration Date unless Landlord requires their removal (including, but not limited to, Alterations pursuant to Section 11). Further, any personal property in the Premises on the Commencement Date, movable or otherwise, unless installed and paid for by Tenant, shall also constitute Landlord’s Property and shall not be removed by Tenant. For purposes of this Lease, any references to “Tenant’s Property” shall mean any personal property for which Tenant has itself paid or manufactured, together with any machinery and equipment for which Tenant has paid and that is not attached to, or built into, the Premises. In no event shall Tenant remove any of the following materials or equipment from the Premises without Landlord’s prior written consent (which consent may be given or withheld in Landlord’s sole discretion): any power wiring or power panels, lighting or lighting fixtures, heaters, air conditioners or any other HVAC equipment, fencing or security gates, or other similar building operating equipment. At or before the Expiration Date, or the date of any earlier termination, Tenant, at its expense, shall remove from the Premises all of Tenant’s Property and any Alterations that Landlord requires be removed pursuant to Section 11, and Tenant shall repair (to Landlord’s reasonable satisfaction) any damage to the Premises or the Property resulting from either or both of such installation and removal. Any other items of Tenant’s Property that remain in the Premises after the Expiration Date, or following an earlier termination date, may, at the option of Landlord, be deemed to have been abandoned, and in such case, such items of Tenant’s Property may be retained by Landlord as its property or be disposed of by Landlord, in Landlord’s sole and absolute discretion and without accountability, at Tenant’s expense. Notwithstanding the foregoing, if Tenant is in default under the terms of this Lease, Tenant may remove Tenant’s Property from the Premises only upon the express written direction of Landlord.
Landlord's Agents If Tenant is in default under this Lease, possession of Tenant's funds or negotiation of Tenant's negotiable instrument by any of Landlord's agents shall not waive any breach by Tenant or any remedies of Landlord under this Lease.