Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Completion of Improvements Within 90 days of completion of any construction herein permitted, Company will cause to be prepared and delivered to Authority record documents as required under the Tenant Work Permit process, including but not limited to as-builts, legal descriptions, boundary surveys, and certified final cost of construction. The submission of record document electronic media will be in accordance with Authority’s Standard Procedure for computer aided design and drafting and drawings, as may be revised from time to time.
Condition of Improvements The risk of destruction or substantial damage by fire or Act of God prior to delivery of deed is assumed by Seller. Xxxxxx agrees that on possession, the Real Estate shall be in the same condition as it is on the date of this contract, except for ordinary wear and tear. If the Real Estate should be damaged or destroyed by fire or other casualty and if, prior to Closing, the real Estate shall not be repaired or restored by and at the Sellers expense, to a condition as good as it was prior to the damage or destruction, then Purchaser, at his option, may terminate this contract by written notice to Seller and the Down Payment Shall be returned to Purchaser. While this contract is pending, Sellers shall not change any existing lease or enter into any new lease, nor make any substantial alterations or repairs without the consent of the Purchaser. In addition, the Purchaser also has an insurable interest in the property from date of this contract. Purchaser is hereby notified that insurance should be placed upon the property immediately to protect Purchasers’ interest.
Landlord’s Remedies Upon occurrence of any default by Tenant under this Lease and (i) if the event of default described in Section 8.1(a) is not cured within five (5) days after written notice from Landlord of such default; provided, however, Landlord shall only be obligated to provide such written notice to Tenant once in each Lease Year and thereafter, Tenant shall be in default if it shall fail to pay any Rent or other monetary charge due from Tenant hereunder as and when due and payable; (ii) if the events described in Sections 8.1(b), (d), (f) and (g) are not cured within thirty (30) days after written notice from Landlord of such default; provided, however, that if the nature of Tenant’s default under Section 8.1(b) is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall be afforded such additional period of time not to exceed an additional thirty (30) days within which to cure such default as shall be reasonable under the circumstance, if and so long as Tenant commenced to cure within the first thirty (30) day period and diligently prosecuted the cure thereof to completion within such additional thirty (30) day period; or (iii) with no additional notice and cure period for events of defaults described in Sections 8.1(c), (e), and (h), the Landlord shall have the option to do and perform any one or more of the following in addition to, and not in limitation of, any other remedy or right permitted it by law or in equity or by this Lease:
(a) Continue this Lease in full force and effect, and this Lease shall continue in full force and effect as long as Landlord does not terminate this Lease, and Landlord shall have the right to collect Rent, Additional Rent and other charges when due.
(b) Terminate this Lease, and Landlord may in accordance within applicable laws forthwith repossess the Premises and be entitled to recover as damages a sum of money equal to the total of (i) the cost of recovering the Premises, (ii) the cost of removing and storing Tenant’s or any other occupant’s property, (iii) the unpaid Rent and any other sums accrued hereunder at the date of termination, (iv) a sum equal to the amount, if any, by which the present value of the total Rent and other benefits which would have accrued to Landlord under this Lease for the remainder of the Term, if the terms of this Lease had been fully complied with by Tenant, discounted at eight percent (8%) per annum exceeds the total fair market value of the Premises for the balance of the Term, also discounted back to present value at eight percent (8%) per annum (it being the agreement of the parties hereto that Landlord shall receive the benefit of its bargain), (v) the cost of reletting the Premises including, without limitation, the cost of restoring the Premises to the condition necessary to rent the Premises at the prevailing market rental rate, normal wear and tear excepted, (vi) any increase in insurance premiums caused by the vacancy of the Premises, (vii) amount of any unamortized improvements to the Premises paid for by Landlord, (viii) the amount of any unamortized brokerage commissions or other costs paid, (ix) the cost of decorations, repairs, changes, alterations and additions to the Premises, (x) the cost of any brokerage fees or commissions payable by Landlord in connection with any reletting or attempted reletting, (xi) any other sum of money or damages owed by Tenant to Landlord. In the event Landlord shall elect to terminate this Lease, Landlord shall at once have all the rights of reentry upon the Premises available under North Carolina law, without becoming liable for damages, or guilty of trespass.
(c) Terminate Tenant’s right of occupancy of the Premises and reenter and repossess the Premises by entry, forcible entry or detainer suit or otherwise, without demand or notice of any kind to Tenant and without terminating this Lease, without acceptance of surrender of possession of the Premises, and without becoming liable for damages or guilty of trespass, in which event Landlord shall use reasonable efforts to relet the Premises or any part thereof for the account of Tenant, but only to the extent provided in Section 8.3 hereinbelow (provided that in no event shall Landlord be under any obligation to relet the Premises before Landlord relets or leases any other portion of the Project or any other property under the ownership or control of Landlord) for a period equal to or lesser or greater than the remainder of the Term of the Lease on whatever terms and conditions as Landlord, at Landlord’s sole discretion, deems advisable. Tenant shall be liable for and shall pay to Landlord all Rent payable by Tenant under this Lease (plus interest at the past due rate provided in Section 3.1(c) of this Lease if in arrears) plus an amount equal to (i) the cost of recovering possession of the Premises, (ii) the reasonable cost of removing and storing any of Tenant’s or any other occupant’s property left on the Premises or the Project after reentry, (iii) the cost of repairs, changes, alterations and additions to the Premises and the Project, (iv) the cost of any attempted reletting or reletting and the collection of the rent accruing from such reletting,
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.
Construction of Improvements Lessee shall construct its planned facilities and install therein all necessary fixtures, equipment, and accessories, all of which shall be in accordance with the terms and conditions of this Lease and any applicable city code or FAA requirements. Lessee shall complete construction of the new improvements within one (1) year after the Effective Date of this Lease. Existing improvements shall be deemed to have been appropriately constructed so long as they are well-maintained and meet all applicable city code and FAA requirements. It is expressly understood that upon the expiration of the Lease, all hangar improvements shall become property of Lessor.
8.1 Lessee agrees to reimburse Lessor for the apportioned costs of roadway improvements including, but not limited to: excavation, paving, drainage, and fencing required for all extensions of the access road to the Leased Premises. Lessee shall be responsible for the cost of all extensions, as applicable, of all water, sewer, and other utilities to the Leased Premises, as well as any fees for obtaining service. Lessee shall be responsible for payment at the time improvements are completed. Lessee shall remit payment to Lessor within thirty (30) days from the date of invoice.
8.2 Lessee agrees to construct, at Lessee’s expense, aircraft access improvements, including without limitation driveways, taxi lanes, aprons, and ramps to its planned facility. Construction and location of the access improvements shall comply with specifications set forth by Lessor at the time of plan’s approval. Lessee understands that those portions of the constructed Airport access improvements situated outside the boundaries of the Leased Premises shall become, immediately upon their completion to Lessor’s satisfaction, the property of Lessor. All construction and any connections to the runway of any apron or taxi lane shall in addition be governed by any rules or regulations regarding Airport operations and must be approved of and overseen by Airport management. Constructed facilities shall not be occupied until access is completed and accepted by Lessor.
8.3 Upon completion of improvements, Lessee shall provide an 8 ½” x 11” site plan detailing a scaled drawing of the Leased Premises, hangar foot print, office area, parking, landscaping, and any other improvements.
8.4 The provisions provided above do not relieve Lessee from compliance with all applicable building code requirements and acquiring all necessary licenses and permits from any governmental authority.
8.5 If the aircraft hangar or other improvements on the Leased Premises are damaged or destroyed, Lessee shall do whatever is necessary to repair, rebuild, or restore the structure and other improvements to substantially the same condition existing prior to the damage or destruction within 180 days of the date of destruction. Upon written request from Lessee, Lessor may extend the 180-day timeline to the extent reasonably necessary due to conditions beyond the control of Lessee.
Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises. Notwithstanding anything to the contrary contained in this Lease, as of the Rent Commencement Date, the maintenance and repair obligations for the Premises shall be allocated between Landlord and Tenant as set forth on Exhibit H attached hereto. The maintenance obligations allocated to Tenant pursuant to Exhibit H (the “Tenant Maintenance Obligations”) shall be performed by Tenant at Tenant’s sole cost and expense. The Tenant Maintenance Obligations shall include the procurement and maintenance of contracts, in form and substance reasonably satisfactory to Landlord, with copies to Landlord upon Landlord’s written request, for and with contractors reasonably acceptable to Landlord specializing and experienced in the respective Tenant Maintenance Obligations. Notwithstanding anything to the contrary contained herein, the scope of work of any such contracts entered into by Tenant pursuant to this paragraph shall, at a minimum, comply with manufacturer’s recommended maintenance procedures for the optimal performance of the applicable equipment. Landlord shall, notwithstanding anything to the contrary contained in this Lease, have no obligation to perform any Tenant Maintenance Obligations. The Tenant Maintenance Obligations shall not include the right or obligation on the part of Tenant to make any structural and/or capital repairs or improvements to the Project, and Landlord shall continue, as part of Operating Expenses, to be responsible, as provided in Section 13, for capital repairs and replacements required to be made to the Project. If Tenant fails to maintain any portion of the Premises for which Tenant is responsible as part of the Tenant Maintenance Obligations in a manner reasonably acceptable to Landlord within the requirements of this Lease, Landlord shall have the right, but not the obligation, to provide Tenant with written notice thereof and to assume the Tenant Maintenance Obligations if Tenant does not cure Tenant’s failure within 10 days after receipt of such notice.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
