EXPANSION PUNCH LIST Sample Clauses

EXPANSION PUNCH LIST. Landlord shall notify Tenant of the date which is approximately seven (7) days prior to the estimated date on which Substantial Completion for the Expansion Space is expected to be achieved (herein referred to as "Expansion Inspection Date"). Landlord and Tenant shall, on the Expansion Inspection Date, make a joint physical inspection of the Expansion Space to list any items of work to be completed or corrected (herein referred to as "Expansion Punch List Items"). Landlord shall deliver, in writing, its promise to complete the Expansion Punch List Items, within such reasonable period of time in respect to each item as is necessary to complete same, taking into account diligence and good workmanlike practices. In the event of a disagreement between the parties as to the inclusion or the exclusion of an item as an Expansion Punch List Item, Tenant and the Expansion Architect shall appoint an Independent Architect to make such determination, and the decision of the Independent Architect (which decision shall be based solely on the determination of whether the item in question was constructed in substantial conformity with the Expansion Plans) shall control.
Sample 1
AutoNDA by SimpleDocs
EXPANSION PUNCH LIST. If Landlord constructs the Expansion Space, Landlord shall notify Tenant of the date which is not less than ten (10) days prior to the estimated date on which Substantial Completion of the Expansion Space is expected to be achieved (herein referred to as "EXPANSION INSPECTION DATE"). As close to the Expansion Inspection Date as is reasonably possible, Landlord and Tenant shall make a joint, physical inspection of the Expansion Space to list any items of work to be completed (herein referred to as "EXPANSION PUNCH LIST ITEMS"). Landlord shall deliver, in writing, its unconditional promise to complete the Expansion Punch List Items, within such reasonable period of time in respect to each item as is necessary to complete the same, taking into account diligence and good workmanlike practices and long lead time items for materials. In the event of a disagreement between the parties as to the inclusion or the exclusion of an item as an Expansion Punch List Item, the decision of the Construction Arbitrator (or if the Construction Arbitrator is unwilling to act or ceases to exist, such successor Construction Arbitrator reasonably and mutually agreed upon by Landlord and Tenant) shall control.
Sample 1
EXPANSION PUNCH LIST. Landlord, Expansion Contractor and Tenant shall, on the date on which the Expansion Improvements are Substantially Completed, make a joint physical inspection of the Expansion Improvements to list the remaining items of work to be completed (“Punch List Items”). Landlord shall cause Expansion Contractor to deliver, in writing, an unconditional promise to complete the Punch List Items within a reasonable period of time in respect to each item, taking into account diligence and good and workmanlike practices. Such time period shall not be longer than sixty (60) days, subject to Permitted Delays (including, without limitation, the inability to obtain supplies or other items on a timely basis and work which is weather-dependent), in the event of which Permitted Delays, Expansion Contractor shall nonetheless diligently pursue the completion of the Punch List Items as promptly as practicable. In the event of a disagreement among or between the parties as to the inclusion or the exclusion of a Punch List Item, the decision of the Expansion Architect, which decision shall be based solely on the determination of whether the item in question was constructed in substantial conformity with the Final Expansion Plans and Specifications shall control.
Sample 1
EXPANSION PUNCH LIST. The inspection of the Expansion Improvements and the determination of Punch List Items with respect thereto shall be conducted and determined in the manner set forth in Section 2.2 hereof, to the extent applicable.
Sample 1

Related to EXPANSION PUNCH LIST

  • Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).

  • Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.

  • Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).

  • Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.

  • Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.

  • Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.

  • Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.

  • Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.

Time is Money Join Law Insider Premium to draft better contracts faster.