Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS in its discretion. If APS determines that the Contractor has failed to perform satisfactorily, then APS will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS to the Contractor (unless APS in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS for all costs incurred by APS after the effective date of termination, including costs required to be expended by APS to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS upon demand by APS. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APS, and APS shall be entitled to recover, all damages to which APS is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS to the Contractor under the Contract and all attorney fees and costs incurred by APS to enforce any provision of this Contract. Except as otherwise directed by APS in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 6 contracts
Samples: Usage and Privacy Agreement, Security Agreement, www.apsva.us
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Subsequent Contract Term(s) and until APS the County determines that all of the following requirements and conditions have been satisfactorily met: APS the County has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS the County shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS the County in its discretion. If APS the County determines that the Contractor has failed to perform satisfactorily, then APS the County will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period Period, or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS the County prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the County Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS The County may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS the County terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS the County to the Contractor (unless APS the County in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS the County for all costs incurred by APS the County after the effective date of termination, including costs required to be expended by APS the County to complete the Work covered by the Contract, including costs of delay in completing the Work Project or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS the County upon demand by APSthe County. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APSthe County, and APS the County shall be entitled to recover, all damages to which APS the County is entitled by this Contract or by law, including, including and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS the County to the Contractor under the Contract and all attorney fees and costs incurred by APS the County to enforce any provision of this Contract. Except as otherwise directed by APS the County in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 4 contracts
Samples: Rider Agreement, Rider Agreement, Rider Agreement
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS City shall have the right to terminate this Contract sooner prior to the Time for Completion if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS the City in its discretion. If APS the City determines that the Contractor has failed to perform satisfactorily, then APS the City will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, Contractor and allocable to the Contract and accepted by APS the City prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the City Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS The City may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS the City terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS the City to the Contractor (unless APS the City in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS the City for all costs incurred by APS the City after the effective date of termination, including costs required to be expended by APS the City to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS the City upon demand by APSthe City. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APSthe City, and APS the City shall be entitled to recover, all damages to which APS the City is entitled by this Contract or by law, including, including and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS the City to the Contractor under the Contract and all attorney fees and costs incurred by APS the City to enforce any provision of this Contract. Except as otherwise directed by APS the City in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. contractor In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 3 contracts
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Subsequent Contract Term(s) and until APS the County determines that all of the following requirements and conditions have been satisfactorily met: APS the County has accepted the all Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS the County shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS the County in its discretion. If APS the County determines that the Contractor has failed to perform satisfactorily, then APS the County will give the Contractor written notice of such failure(s) failure/s and the opportunity to cure such failure(s) failure/s within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS the County prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the County Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS The County may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS the County terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS the County to the Contractor (unless APS the County in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS the County for all costs incurred by APS the County after the effective date of termination, termination including costs required to be expended by APS the County to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS the County upon demand by APSthe County. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APSthe County, and APS the County shall be entitled to recover, all damages to which APS the County is entitled by this Contract or by law, including, including and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS the County to the Contractor under the Contract and all attorney fees and costs incurred by APS the County to enforce any provision of this Contract. Except as otherwise directed by APS the County in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 2 contracts
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS City shall have the right to terminate this Contract sooner prior to the Time for Completion if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS the City in its discretion. If APS the City determines that the Contractor has failed to perform satisfactorily, then APS the City will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, Contractor and allocable to the Contract and accepted by APS the City prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the City Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS The City may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS the City terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS the City to the Contractor (unless APS the City in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS the City for all costs incurred by APS the City after the effective date of termination, including costs required to be expended by APS the City to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS the City upon demand by APSthe City. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APSthe City, and APS the City shall be entitled to recover, recover all damages to which APS the City is entitled by this Contract or by law, including, including and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS the City to the Contractor under the Contract and all attorney fees and costs incurred by APS the City to enforce any provision of this Contract. Except as otherwise directed by APS the City in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. Contractor In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 2 contracts
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor CMA has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS shall have the right to terminate this Contract sooner if the Contractor CMA is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS in its discretion. If APS determines that the Contractor CMA has failed to perform satisfactorily, then APS will give the Contractor CMA written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor CMA fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the ContractorCMA’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor CMA may apply for compensation for Contract services satisfactorily performed by the ContractorCMA, allocable to the Contract and accepted by APS prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to To be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor CMA of same within a reasonable time thereafter. If APS terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS to the Contractor CMA (unless APS in its discretion provides for an opportunity to cure) and the Contractor CMA shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor CMA shall be liable to APS for all costs incurred by APS after the effective date of termination, including costs required to be expended by APS to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor CMA or its subcontractors. Such costs shall be either deducted from any amount due the Contractor CMA or shall be promptly paid by the Contractor CMA to APS upon demand by APS. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APS, and APS shall be entitled to recover, all damages to which APS is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS to the Contractor CMA under the Contract and all attorney fees and costs incurred by APS to enforce any provision of this Contract. Except as otherwise directed by APS in the notice, the Contractor CMA shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the ContractorCMA. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 2 contracts
Samples: www.apsva.us, www.apsva.us
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term Period or any Renewal Contract Term(sOption Year(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS in its discretion. If APS determines that the Contractor has failed to perform satisfactorily, then APS will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS to the Contractor (unless APS in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS for all costs incurred by APS after the effective date of termination, including costs required to be expended by APS to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS upon demand by APS. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APS, and APS shall be entitled to recover, all damages to which APS is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS to the Contractor under the Contract and all attorney fees and costs incurred by APS to enforce any provision of this Contract. Except as otherwise directed by APS in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 1 contract
Samples: www.apsva.us
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor CMA has met all requirements and conditions relating to the Work under the Contract Documents, Documents including warranty and guarantee periods. However, APS shall have the right to terminate this Contract sooner if the Contractor CMA is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS in its discretion. If APS determines that the Contractor CMA has failed to perform satisfactorily, then APS will give the Contractor CMA written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor CMA fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the ContractorCMA’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor CMA may apply for compensation for Contract services satisfactorily performed by the ContractorCMA, allocable to the Contract and accepted by APS prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to To be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor CMA of same within a reasonable time thereafter. If APS terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS to the Contractor CMA (unless APS in its discretion provides for an opportunity to cure) and the Contractor CMA shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor CMA shall be liable to APS for all costs incurred by APS after the effective date of termination, including costs required to be expended by APS to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor CMA or its subcontractors. Such costs shall be either deducted from any amount due the Contractor CMA or shall be promptly paid by the Contractor CMA to APS upon demand by APS. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APS, and APS shall be entitled to recover, all damages to which APS is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS to the Contractor CMA under the Contract and all attorney fees and costs incurred by APS to enforce any provision of this Contract. Except as otherwise directed by APS in the notice, the Contractor CMA shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the ContractorCMA. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 1 contract
Samples: www.apsva.us
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS the County determines that all of the following requirements and conditions have been satisfactorily met: APS the County has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS the County shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS the County in its discretion. If APS the County determines that the Contractor has failed to perform satisfactorily, then APS the County will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS the County prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS the County Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS The County may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS the County terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS the County to the Contractor (unless APS the County in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS the County for all costs incurred by APS the County after the effective date of termination, including costs required to be expended by APS the County to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS the County upon demand by APSthe County. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APSthe County, and APS the County shall be entitled to recover, all damages to which APS the County is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS the County to the Contractor under the Contract and all attorney fees and costs incurred by APS the County to enforce any provision of this Contract. Except as otherwise directed by APS the County in the notice, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 1 contract
Samples: Agreement
Termination for Cause Including Breach and Default Cure. The Contract shall remain in force for the Initial Contract Term or any Renewal Contract Term(s) and until APS determines that all of the following requirements and conditions have been satisfactorily met: APS has accepted the Work, and thereafter until the Contractor has met all requirements and conditions relating to the Work under the Contract Documents, including warranty and guarantee periods. However, APS shall have the right to terminate this Contract sooner if the Contractor is in breach or default or has failed to perform satisfactorily the Work required, as determined by APS in its discretion. If APS determines that the Contractor has failed to perform satisfactorily, then APS will give the Contractor written notice of such failure(s) and the opportunity to cure such failure(s) within at least fifteen (15) days before termination of the Contract takes effect (“Cure Period”). If the Contractor fails to cure within the Cure Period or as otherwise specified in the notice, the Contract may be terminated for the Contractor’s failure to provide satisfactory Contract performance. Upon such termination, the Contractor may apply for compensation for Contract services satisfactorily performed by the Contractor, allocable to the Contract and accepted by APS prior to such termination unless otherwise barred by the Contract (“Termination Costs”). In order to be considered, such request for Termination Costs, with all supporting documentation, must be submitted to APS Project Officer within fifteen (15) calendar days after the expiration of the Cure Period. APS may accept or reject, in whole or in part, the application for Termination Costs and notify the Contractor of same within a reasonable time thereafter. If APS terminates the Contract for default or breach of any Contract provision or condition, then the termination shall be immediate after notice from APS to the Contractor (unless APS in its discretion provides for an opportunity to cure) and the Contractor shall not be permitted to seek Termination Costs. Upon any termination pursuant to this section, the Contractor shall be liable to APS for all costs incurred by APS after the effective date of termination, including costs required to be expended by APS to complete the Work covered by the Contract, including costs of delay in completing the Work or the cost of repairing or correcting any unsatisfactory or non-compliant work performed or provided by the Contractor or its subcontractors. Such costs shall be either deducted from any amount due the Contractor or shall be promptly paid by the Contractor to APS upon demand by APS. Additionally, and notwithstanding any provision in this Contract to the contrary, the Contactor is liable to APS, and APS shall be entitled to recover, all damages to which APS is entitled by this Contract or by law, including, and without limitation, direct damages, indirect damages, consequential damages, delay damages, replacement costs, refund of all sums paid by APS to the Contractor under the Contract and all attorney fees and costs incurred by APS to enforce any provision of this Contract. Except as otherwise directed by APS in the notice, if practicable, the Contractor shall stop work on the date of receipt of notice of the termination or other date specified in the notice, place no further orders or subcontracts for materials, services, or facilities except as are necessary for the completion of such portion of the Work not terminated, and terminate all vendors and subcontracts and settle all outstanding liabilities and claims. Any purchases after the date of termination contained in the notice shall be the sole responsibility of the Contractor. In the event any termination for cause, default, or breach shall be found to be improper or invalid by any court of competent jurisdiction then such termination shall be deemed to have been a termination for convenience.
Appears in 1 contract
Samples: Security Agreement