Termination for Causing Failure of Critical Services Sample Clauses

Termination for Causing Failure of Critical Services. If Perot Systems (1) as a result of a breach of its obligatioxx xxder this Agreement causes the failure of any specific Critical Service described in Schedule 7.8 and (2) does not cure such failure with a permanent solution within the number of hours identified in Schedule 7.8 as the applicable cure period, after receipt of a notice from Ca1IPX with respect to such failure, more than the number of disruptions in a six month time period set forth in Schedule 7.8 for that Critical Service, then CalPX may, upon notice to Perot Systems, terminate this Agreement, in whole or in paxx, xs of the termination date specified in the notice. For the purposes of this Section 7.8, such failures caused by Perot Systems shall not be counted as a disruption (i) during the Transition Period, (ii) prior to the date a disaster recovery solution is completed, (iii) to the extent the failure of a Critical Service is caused by the failure to complete all Required Improvements, (iv) in connection with any failure caused by a server that has not had its scheduled maintenance window made available by CalPX during the 30 day period prior to the disruption, (v) if Perot Systems' inability to cure the failure is caused by xxx xhird party's failure or inability to provide software, hardware or services necessary for Perot Systems to cure the failure, (vi) in connection with xxx failure of a Critical Service caused by the installation of new hardware or software that occurs within 30 days after such installation, or (vii) in connection with any failure to provide a Critical Service caused by a Force Majeure Event.
Sample 1
AutoNDA by SimpleDocs

Related to Termination for Causing Failure of Critical Services

  • CFR PART 200 Termination Termination for cause and for convenience by the grantee or subgrantee including the manner by which it will be effected and the basis for settlement. (All contracts in excess of $10,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for cause after giving the vendor an appropriate opportunity and up to 30 days, to cure the causal breach of terms and conditions. ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for convenience with 30 days notice in writing to the awarded vendor. The vendor would be compensated for work performed and goods procured as of the termination date if for convenience of the ESC Region 8 and TIPS Members. Any award under this procurement process is not exclusive and the ESC Region 8 and TIPS reserves the right to purchase goods and services from other vendors when it is in the best interest of the ESC Region 8 and TIPS. Does vendor agree? Yes

  • Termination for Non-Appropriation The continuation of this Contract beyond the current fiscal year is subject to and contingent upon sufficient funds being appropriated, budgeted, and otherwise made available by the City. The City may terminate this Contract, and Contractor waives any and all claim(s) for damages, effective immediately upon receipt of written notice (or any date specified therein) if for any reason the City’s funding from State and/or federal sources is not appropriated or is withdrawn, limited, or impaired.

  • Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.

  • Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • Termination for Material Breach Either Party (the “Terminating Party”) may terminate this Agreement in its entirety, or on a country-by-country and Product-by-Product basis, in the event the other Party (the “Breaching Party”) has materially breached this Agreement, and such material breach has not been cured within sixty (60) days after receipt of written notice of such breach by the Breaching Party from the Terminating Party (the “Cure Period”). The written notice describing the alleged material breach shall provide sufficient detail to put the Breaching Party on notice of such material breach. Any termination of this Agreement pursuant to this Section 10.3 shall become effective at the end of the Cure Period, unless the Breaching Party has cured any such material breach prior to the expiration of such Cure Period; provided that in the event a claim of material breach is being contested diligently and in good faith by appropriate proceedings hereunder, any termination pursuant to this Section shall not become effective unless and until such material breach has been established in such proceedings and, in the event that, following such establishment, a cure may then be accomplished by the payment of money or the taking of certain actions, such payment or actions are not paid or taken within sixty (60) days of the conclusion of such proceedings. The right of either Party to terminate this Agreement as provided in this Section 10.3 shall not be affected in any way by such Party’s waiver of or failure to take action with respect to any previous breach under this Agreement.

  • Termination for continuing Force Majeure Event Either Party may, by written notice to the other, terminate this Framework Agreement if a Force Majeure Event endures for a continuous period of more than one hundred and twenty (120) Working Days.

  • Term Termination 10.1. This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein. 10.2. This Agreement shall terminate in accordance with the following provisions: (a) At the option of the Company or the Trust at any time from the date hereof upon 180 days’ notice, unless a shorter time is agreed to by the parties; (b) At the option of the Company or the Trust, if Fund shares are not reasonably available to meet the requirements of the Variable Contracts. Prompt notice of election to terminate shall be furnished by the Company. The termination will be effective ten days after receipt of notice unless the Trust makes available a sufficient number of Fund shares to reasonably meet the requirements of the Variable Contracts within the ten-day period; (c) At the option of the Company, upon the institution of formal proceedings against the Trust, the Distributor or Adviser by the SEC, FINRA, or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in the Company’s reasonable judgment, materially impair the Trust’s, the Distributor’s or the Adviser’s ability to meet and perform their respective obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by the Company with said termination to be effective upon receipt of notice; (d) At the option of the Trust, the Distributor or the Adviser, upon the institution of formal proceedings against the Company by the SEC, FINRA, or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in Trust’s reasonable judgment, materially impair the Company’s ability to meet and perform its obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by Trust with said termination to be effective upon receipt of notice; (e) At the option of the Company, in the event the Trust’s shares are not registered, issued or sold in accordance with applicable state or federal law, or such law precludes the use of such shares as the underlying investment medium of Variable Contracts issued or to be issued by the Company. Termination shall be effective immediately upon notice to the Trust; (f) At the option of the Trust if the Variable Contracts cease to qualify as annuity contracts or life insurance contracts, as applicable, under the Code, or if the Trust reasonably believes that the Variable Contracts may fail to so qualify. Termination shall be effective upon receipt of notice by the Company; (g) At the option of the Company, upon the Trust’s breach of any material provision of this Agreement, which breach has not been cured to the satisfaction of the Company within ten days after written notice of such breach is delivered to the Trust; (h) At the option of the Trust, upon the Company’s breach of any material provision of this Agreement, which breach has not been cured to the satisfaction of the Trust within ten days after written notice of such breach is delivered to the Company; (i) At the option of the Trust, if the Variable Contracts are not registered, issued or sold in accordance with applicable federal and/or state law. Termination shall be effective immediately upon such occurrence without notice to the Company; (j) At the option of the Company in the event that any Fund ceases to qualify as a Regulated Investment Company under Subchapter M of the Code or under any successor or similar provision, or if the Company reasonably believes that any Fund may fail to so qualify. Termination shall be effective immediately upon notice to the Trust; (k) At the option of the Company in the event that any Fund fails to meet the diversification requirements specified in Article II hereof or if the Company reasonably believes that any Fund may fail to meet such diversification requirements. Termination shall be effective immediately upon notice to the Trust; and (l) In the event this Agreement is assigned without the prior written consent of the Company, the Trust, the Distributor and the Adviser, termination shall be effective immediately upon such occurrence without notice. 10.3. Notwithstanding any termination of this Agreement pursuant to Section 10.2 hereof, the Trust shall, at the option of the Company, continue to make available additional Fund shares, as provided below, for so long as the Company desires pursuant to the terms and conditions of this Agreement, for all Variable Contracts in effect on the effective date of termination of this Agreement (“Existing Contracts”). Specifically, without limitation, if the Company so elects to make additional Fund shares available, the owners of the Existing Contracts or the Company, whichever shall have legal authority to do so, shall be permitted to reallocate investments in the Trust, redeem investments in the Trust and/or invest in the Trust upon the payment of additional premiums under the Existing Contracts. In the event of a termination of this Agreement, the Company, as promptly as is practicable under the circumstances, shall notify the Trust, the Distributor and the Adviser whether the Company elects to continue to make Fund shares available after such termination. If Fund shares continue to be made available after such termination, the provisions of this Agreement shall remain in effect. 10.4. Except as necessary to implement Variable Contract owner initiated transactions, or as required by state insurance laws or regulations, the Company shall not redeem the shares attributable to the Variable Contracts (as opposed to the shares attributable to the Company’s assets held in the Separate Accounts or invested directly), and the Company shall not prevent Variable Contract owners from allocating payments to a Fund that was otherwise available under the Variable Contracts, until thirty (30) days after the Company shall have notified the Trust of its intention to do so.

  • Grantee Responsibility for System Agency’s Termination Costs If the System Agency terminates the Grant Agreement for cause, the Grantee shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Grantee. These costs include, but are not limited to, the costs of procuring a substitute grantee and the cost of any claim or litigation attributable to Xxxxxxx’s failure to perform any work in accordance with the terms of the Grant Agreement.

  • CFR PART 200 Termination Termination for cause and for convenience by the grantee or subgrantee including the manner by which it will be eff ected and the basis for settlement. (All contracts in excess of $10,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for cause after giving the vendor an appropriate opportunity an d up to 30 days, to cure the causal breach of terms and conditions. ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for convenience with 30 days notice in writing to the awarded vendor. The vendor would be compensated for work performed and goods procured as of the termination date if for convenience of the ESC Region 8 and TIPS Members. Any award under this procurement process is not exclusive and the ESC Region 8 and TIPS reserves the right to purchase goods and services from other vendors when it is in the best interest of t he ESC Region 8 and TIPS. Does vendor agree? Yes

  • Termination for Cause with Notice to Cure Requirement Contractor may terminate this contract for the Department’s failure to perform any of its duties under this contract after giving the Department written notice of the failure. The written notice must demand performance of the stated failure within a specified period of time of not less than 30 days. If the demanded performance is not completed within the specified period, the termination is effective at the end of the specified period.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!