Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Commencement and Completion The Work shall commence on _______________, 20__ and shall be complete in accordance with this Agreement without delay on ______________, 20__. The term “day”, used throughout this Agreement, refers to calendar days. Contractor shall not be entitled to any additional compensation for any Permitted Delays. If this Agreement is not signed and returned to the Owner before any work commences, this Agreement will be considered as accepted as presented to the Contractor.
Pre-Commencement Phase Services The services required to be provided by the Contractor for the Pre- Commencement Phase of the Project in accordance with the Contract Documents.
Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.
Termination; General The Representatives may terminate this Agreement, by notice to the Company, at any time at or prior to Closing Time (i) if in the reasonable judgment of the Representatives, there has been, since the time of execution of this Agreement or since the respective dates as of which information is given in the Prospectus or the General Disclosure Package, any material adverse change in the condition, financial or otherwise, or in the earnings, business affairs, financial prospects or business prospects of the Company and its subsidiaries considered as one enterprise, whether or not arising in the ordinary course of business, or (ii) if there has occurred any material adverse change in the financial markets in the United States or the international financial markets, any outbreak of hostilities or escalation thereof or other calamity or crisis or any change or development involving a prospective change in national or international political, financial or economic conditions, in each case the effect of which is such as to make it, in the judgment of the Representatives, impracticable or inadvisable to market the Securities or to enforce contracts for the sale of the Securities, or (iii) if trading in any securities of the Company has been suspended or limited by the Commission, the New York Stock Exchange or the Nasdaq Global Market, or if trading generally on the NYSE American or the New York Stock Exchange or in the Nasdaq Global Market has been suspended or limited, or minimum or maximum prices for trading have been fixed, or maximum ranges for prices have been required, by any of said exchanges or by such system or by order of the Commission, the FINRA or any other governmental authority, or a material disruption has occurred in commercial banking or securities settlement or clearance services in the United States, or (iv) if a banking moratorium has been declared by either Federal, California or New York authorities, or (v) if since the date of this Agreement, there has occurred a downgrading in the rating assigned to the Securities, any class or series of the Company’s outstanding Preferred Stock, if any, or any of the Company’s other debt securities by any nationally recognized securities rating agency, or any such securities rating agency has publicly announced that it has under surveillance or review, with possible negative implications or without indicating the direction of the possible change, its rating of the Securities, any class or series of Preferred Stock or any of the Company’s other debt securities.
Vesting Commencement Date Exercise Price per Share: Total Number of Shares Subject to the Option: Total Exercise Price: Expiration Date:
Commencement and Completion of Work The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Failure to commence work in a timely manner and/or diligently pursue work to completion may be grounds for termination of this Agreement.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County.
2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract.
2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief.
2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
Effective Date of This Agreement and Termination Thereof (a) This Agreement shall become effective at 10:00 a.m., New York time, on the first full business day following the day on which you and the Company receive notification that the Registration Statement became effective.
(b) This Agreement may be terminated by the Underwriter by notifying the Company at any time on or before the Closing Date, if any domestic or international event or act or occurrence has in your sole opinion, materially disrupted, or in your sole opinion will in the immediate future materially disrupt, securities markets; or if trading on the New York Stock Exchange, the American Stock Exchange, or in the over-the-counter market shall have been suspended, or minimum or maximum prices for trading shall have been fixed; or if a moratorium in foreign exchange trading by major international banks or persons has been declared; or if the Company shall have sustained a loss material or substantial to the Company taken as a whole by fire, flood, accident, hurricane, earthquake, theft, sabotage or other calamity or malicious act which, whether or not such loss shall have been insured, will, in your sole opinion, make it inadvisable to proceed with the delivery of the Shares; or if there shall have been a material adverse change in the conditions of the securities market in general, as in your reasonable judgment would make it inadvisable to proceed with the offering, sale and delivery of the Shares; or if there shall have been a material adverse change in the financial or Securities markets, particularly in the over-the-counter market having occurred since the date of this Agreement.
(c) If you elect to prevent this Agreement from becoming effective or to terminate this Agreement as provided in this Paragraph 10, the Company shall be notified promptly by you by telephone or facsimile, confirmed by letter.
(d) If this Agreement shall not become effective or if this Agreement shall not be carried out within the time specified herein by reason of any failure on the part of the Company to perform any undertaking, or to materially satisfy any condition of this Agreement by it to be performed or satisfied, the sole liability of the Company to the Underwriter, in addition to the obligations assumed by the Company pursuant to Paragraph 8 herein, will be to reimburse the Underwriter for such reasonable out-of-pocket expenses of the Underwriter in connection with this Agreement and the proposed offering of the Shares.
Project Commencement The Grantee shall begin the grant-funded project <<on or before insert date>> <<within 90 days of the original start date of the grant term or grant execution date, whichever is later,>>, unless otherwise approved by System Agency. If project commencement is delayed, the Grantee must submit in writing to the assigned contract manager, the steps taken to initiate the project, the reasons for the delay, and the expected start date. System Agency may require Grantee to take immediate remedial or corrective action in response to any delay.
