GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
Preservation of Sellers’ Rights of Recovery Without the prior written consent of the Sellers, the Purchasers shall not amend or modify or grant a waiver under (or agree to amend or modify or grant a waiver under) any Serviced Corporate Trust Contract with respect to any Serviced Appointment in a manner that would materially reduce or materially alter the rights of the Sellers to indemnification, reimbursement or recovery for any costs and expenses incurred by the Sellers or their Affiliates or agents (other than the Purchasers in their capacity as Servicer hereunder) from the sponsor, issuer, obligor, depositor or other source of funds available under the terms of any such Serviced Corporate Trust Contract. Notwithstanding the foregoing, such amendment, modification or waiver shall not require the Sellers’ consent if the Purchasers agree in their sole discretion to indemnify the Sellers to the extent such amendment, modification or waiver reduces the Sellers’ available indemnification, reimbursement or recovery for costs and expenses under the terms of any such Serviced Corporate Trust Contract.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Restoration of Rights on Abandonment of Proceedings In case the Trustee shall have proceeded to enforce any right under this Indenture and such proceedings shall have been discontinued or abandoned for any reason, or shall have been determined adversely to the Trustee, then and in every such case the Issuer and the Trustee shall be restored respectively to their former positions and rights hereunder, and all rights, remedies and powers of the Issuer, the Trustee and the Securityholders shall continue as though no such proceedings had been taken.
Secured Party’s Rights and Remedies If at any time (1) an Event of Default or Specified Condition with respect to the Pledgor has occurred and is continuing or (2) an Early Termination Date has occurred or been designated as the result of an Event of Default or Specified Condition with respect to the Pledgor, then, unless the Pledgor has paid in full all of its Obligations that are then due, the Secured Party may exercise one or more of the following rights and remedies:
(i) all rights and remedies available to a secured party under applicable law with respect to Posted Collateral held by the Secured Party;
(ii) any other rights and remedies available to the Secured Party under the terms of Other Posted Support, if any;
(iii) the right to Set-off any amounts payable by the Pledgor with respect to any Obligations against any Posted Collateral or the Cash equivalent of any Posted Collateral held by the Secured Party (or any obligation of the Secured Party to Transfer that Posted Collateral); and
(iv) the right to liquidate any Posted Collateral held by the Secured Party through one or more public or private sales or other dispositions with such notice, if any, as may be required under applicable law, free from any claim or right of any nature whatsoever of the Pledgor, including any equity or right of redemption by the Pledgor (with the Secured Party having the right to purchase any or all of the Posted Collateral to be sold) and to apply the proceeds (or the Cash equivalent thereof) from the liquidation of the Posted Collateral to any amounts payable by the Pledgor with respect to any Obligations in that order as the Secured Party may elect. Each party acknowledges and agrees that Posted Collateral in the form of securities may decline speedily in value and is of a type customarily sold on a recognized market, and, accordingly, the Pledgor is not entitled to prior notice of any sale of that Posted Collateral by the Secured Party, except any notice that is required under applicable law and cannot be waived.
Invoicing for Charges Against the Judicial Council’s Master Account A. The Contractor shall establish a Master Account for the Judicial Council’s charges provided for under the exhibits of this Agreement.
B. Charges to the Master Account shall be settled with Citibank CMC, as defined herein.
C. The Contractor's final invoice for the Master Account shall include the Judicial Council Contract Number set forth on the face of this Agreement and shall be itemized to show the applicable and allowable charges by date and event/category/activity and number served, as appropriate.
D. For performing the Work of this Agreement, the Contractor shall xxxx the Judicial Council for the total actual charges against the Master Account, based upon the prices stated herein and itemized to provide the following details, if applicable:
i. Sleeping room charges as set forth in Exhibit C;
ii. Meeting room rental charges as set forth in Exhibit D;
iii. Food and beverage charges as set forth in Exhibit E; and/or
iv. Charges for miscellaneous requirements as set forth in Exhibit F.
E. If the Contract is terminated in whole or in part, pursuant to either the termination for cause provision or the Judicial Council’s obligation subject to availability of funds provision, as set forth in Exhibit A, the Contactor shall xxxx the Judicial Council for only those applicable and allowable charges accrued up to the effective date of termination, itemized as set forth above in this provision.
F. If the Contract is terminated pursuant to the Termination Fee charge provision, as set forth in Exhibit B, the Contractor shall xxxx the Judicial Council for the allowable and applicable Termination Fee, as set forth in Table 2, below, and shall offset the Termination Fee by rental charges for the meeting and function rooms that the Contractor received from Third Parties during the Program
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
Trustee May Enforce Claims Without Possession of Notes All rights of action and claims under this Indenture or the Notes may be prosecuted and enforced by the Trustee without the possession of any of the Notes or the production thereof in any proceeding relating thereto, and any such proceeding instituted by the Trustee shall be brought in its own name as trustee of an express trust, and any recovery of judgment shall, after provision for the payment of the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel, be for the ratable benefit of the Holders of the Notes in respect of which such judgment has been recovered.
Trustee May Enforce Claims Without Possession of Certificates All rights of action and claims under this Agreement or the Certificates may be prosecuted and enforced by the Trustee without the possession of any of the Certificates or the production thereof in any proceeding relating thereto, and such preceding instituted by the Trustee shall be brought in its own name or in its capacity as Trustee. Any recovery of judgment shall, after provision for the payment of the reasonable compensation, expenses, disbursement and advances of the Trustee, its agents and counsel, be for the ratable benefit of the Certificateholders in respect of which such judgment has been recovered.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
