Assistance by COUNTY STAFF 1.3.1. County shall assign an appropriate staff member to work with A-E in connection with the work of this Contract. Said staff member's duties will consist of the giving of advice and consultations, assisting A-E in negotiations with other public agencies and private parties, miscellaneous items which in the judgment of A-E or County's staff warrant attention, and all other duties as may be described in Attachment A.
1.3.2. All of the above activities, however, shall be the primary responsibility of A-E to schedule, initiate and carry through to completion.
County Responsibilities 5.1 The COUNTY shall designate a COUNTY staff member to act as COUNTY’s Project Manager. It is agreed to by the parties that the COUNTY’s Project Manager will decide all questions, difficulties, or disputes, of whatever nature, which may arise relative to the interpretation of the plans, construction, prosecution and fulfillment of the Scope of Services, and as to the character, quality, amount and value of any work done, and materials furnished, under or by reason of this Agreement. The COUNTY’s Project Manager may appoint representatives as desired that will be authorized to inspect all work done and all materials furnished.
5.2 The COUNTY shall pay in accordance with the provisions set forth in this Agreement.
5.3 The COUNTY retains the right to inspect all work to verify compliance with the contract documents. Such inspection may extend to all or any part of the work and to the manufacture, preparation or fabrication of the materials to be used.
REGULAR SERVICES BY COUNTY 23 1. COUNTY, through its Sheriff-Coroner and deputies, officers and employees, 24 hereinafter referred to as “SHERIFF”, shall render to CITY law enforcement 25 services as hereinafter provided. Such services shall include the 26 enforcement of lawful State statutes and lawful municipal ordinances of 27 CITY other than licensing ordinances.
Office of Foreign Assets Control Neither the Company nor any Subsidiary nor, to the Company’s knowledge, any director, officer, agent, employee or affiliate of the Company or any Subsidiary is currently subject to any U.S. sanctions administered by the Office of Foreign Assets Control of the U.S. Treasury Department (“OFAC”).
THE CITY OF LINCOLN, NEBRASKA ATTEST: City Clerk CITY OF LINCOLN, NEBRASKA Xxxxxxx Xxxxxx Xxxxx, Mayor Approved by Executive Order No. dated
LANCASTER COUNTY, NEBRASKA Contract Approved as to Form:
County The term COUNTY refers to the Board of County Commissioners of Lee County, a charter County and political subdivision of the State of Florida, and any official or employee duly authorized to act on the COUNTY'S behalf relative to this Agreement.
School District For purposes of administering this Agreement, the term "School District" shall mean the School Board or its designated representative.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.
