Other Legal Actions The actions stipulated in this Integrity Pact are without prejudice to any other legal action that may follow in accordance with the provisions of the extant law in force relating to any civil or criminal proceedings.
Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.
Exclusion of Consequential Damages Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.
Exclusion of Consequential Loss Except as expressly provided otherwise in clause 27 or the IRMP Provisions which form part of this Agreement under clause 3, neither Party is liable to the other under or in connection with this Agreement (including under an indemnity) for any Consequential Loss however caused (including any breach of this Agreement or negligent act or omission of a Party).
Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.
Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
