Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Technical Specifications and Drawings a) The Goods and Related Services supplied under this Contract shall conform to the technical specifications and standards mentioned in Section VI, Schedule of Requirements and, when no applicable standard is mentioned, the standard shall be equivalent or superior to the official standards whose application is appropriate to the Goods' country of origin. b) The Supplier shall be entitled to disclaim responsibility for any design, data, drawing, specification or other document, or any modification thereof provided or designed by or on behalf of the Procuring Entity, by giving a notice of such disclaimer to the Procuring Entity. c) Wherever references are made in the Contract to codes and standards in accordance with which it shall be executed, the edition or the revised version of such codes and standards shall be those specified in the Schedule of Requirements. During Contract execution, any changes in any such codes and standards shall be applied only after approval by the Procuring Entity and shall be treated in accordance with GCC Clause 33.
Geotechnical Engineer « »« » « » « » « » « »
OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of-way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections 4, 6(a), 6(b), 6(c), and 7 of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra- State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C.
Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (JUN 2020) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).
PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board of Education agrees to pay the actual tuition costs of courses taken by a teacher at accredited colleges or universities up to three courses per two (2) year fiscal periods from July 1, 2006 to June 30, 2008 and July 1, 2008 to June 30, 2010 respectively, except as follows: 1. No teacher may be reimbursed for courses taken during the first year of teaching in Vineland. 2. Teachers taking courses in the second and third years of employment in Vineland will not receive remuneration until tenure has been secured. The remuneration will then be retroactive and will be paid to the teacher in a lump sum within sixty (60) days after the teacher has secured tenure. 3. All courses must be pre-approved by the Superintendent or his designee subject to the following requirements: (a) A teacher must provide official documentation that he/she has obtained a grade of B or better; (b) Reimbursement shall be paid only for courses directly related to teacher’s teaching field which increase the teacher’s content knowledge and are related to the teacher’s current certification, as determined by the Superintendent or his/her designee in his/her sole discretion; no reimbursement shall be paid for courses leading to a post graduate or professional degree in a field other than education or teaching. Further, effective September 1, 2010, all newly hired teachers shall not be eligible for reimbursement until they are tenured, and they shall not be eligible for retroactive reimbursement upon gaining tenure for courses taken prior to being tenured. (c) The maximum total payments to be made by the Board shall not exceed $130,000.00. Courses shall be applied for no earlier than the following dates: Summer Session - April 1 Fall/Winter Session - June 1 Spring Session - October 1 Courses must, as set forth hereinabove in this sub-article 18.A.3, be pre-approved by the Superintendent or his designee, prior to the teacher commencing the course(s); and (d) Teacher taking courses shall sign a contract requiring them to reimburse the Board for all tuition paid for a course if the teacher shall voluntarily leave the employ of the Board within one (1) full school/academic year of completion of said course, except that reimbursement shall not be required when the teacher shall voluntarily leave the employ of the Board due to a significant, documented life change. 4. Tuition reimbursement costs shall be a sum not to exceed the actual cost of college credits charged in an accredited public State college/University of the State of New Jersey. B. When the Superintendent initiates in-service training courses, workshops, conferences and programs designed to improve the quality of instruction, the cooperation of the Vineland Education Association will be solicited. Notwithstanding the above, the initiation of in-service training courses, workshops, conferences and programs shall be determined solely at the discretion of the Board. C. One professional leave day may be granted to a teacher upon request, according to the following guidelines: 1. The professional day may be for attendance at a workshop, seminar or visit to another school for the expressed purpose of self professional improvement for the job. 2. The request shall arrive in the office of the Superintendent of Schools at least ten (10) working days prior to the date requested and shall be reviewed by the immediate supervisor prior to submission. The Board reserves the right to deny a professional leave day before or immediately following a holiday or on a day which by its nature suggests a hardship for providing a substitute. 3. No more than two teachers from any one elementary school or from any one department in the secondary schools may be granted a professional leave for a given day. 4. The teacher may be required to submit a report to the Superintendent of Schools, Assistant Superintendent, supervisor (s), principal and staff regarding the activity of the professional day. 5. Costs incurred by the teacher for the professional day authorized under this Section shall be the teacher’s responsibility. 6. A maximum of 90 professional leave days may be authorized for the school year which shall be apportioned as follows: elementary, 35; grades seven and eight, 20; and high school, 35. D. If the Board initiates a teacher’s attendance at a professional workshop, seminar or visit, the expenses shall be the responsibility of the Board. Further, this day shall not be subtracted from the 90 professional leave days granted to teachers of the Association. E. The Board agrees to pay the full cost of courses taken by secretaries related to skills and knowledge improvement when such courses are required and approved by the Board. F. The Board and the Association agree that it is important to communicate when developing and implementing current and future learning technologies, including but not limited to distance and on-line learning.
Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.