The TCEQ. The Professional shall prepare and submit to the TCEQ for approval of design plans through the TCEQ Portal.
The TCEQ Sample Clauses
Related to The TCEQ
Weighing and Scaling Costs Purchaser agrees to pay for all weighing costs for logs delivered regardless if logs are purchased on a weight or scale basis. In addition, Purchaser agrees to pay for all scaling costs for logs delivered on a scale basis. Purchaser also agrees to pay for all costs associated with the transmission and reporting of scale or weight data.
Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of-way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections 4, 6(a), 6(b), 6(c), and 7 of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra- State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C.
Procurement of Goods and Services (a) If the HSP is subject to the procurement provisions of the BPSAA, the HSP will abide by all directives and guidelines issued by the Management Board of Cabinet that are applicable to the HSP pursuant to the BPSAA. (b) If the HSP is not subject to the procurement provisions of the BPSAA, the HSP will have a procurement policy in place that requires the acquisition of supplies, equipment or services valued at over $25,000 through a competitive process that ensures the best value for funds expended. If the HSP acquires supplies, equipment or services with the Funding it will do so through a process that is consistent with this policy.
Dewatering (a) Where the whole of a site is so affected by surface water following a period of rain that all productive work is suspended by agreement of the Parties, then dewatering shall proceed as above with Employees so engaged being paid at penalty rates as is the case for safety rectification work. This work is typically performed by Employees engaged within CW1, CW2 or CW3 classifications. When other Employees are undertaking productive work in an area or areas not so affected then dewatering will only attract single time rates. (b) Where a part of a site is affected by surface water following a period of rain, thus rendering some areas unsafe for productive work, consistent with the Employer’s obligations under the OH&S Act, appropriate Employees shall assist in the tidying up of their own work site or area if it is so affected. Where required, appropriate Employees will be provided with the appropriate PPE. Such work to be paid at single time rates. Productive work will continue in areas not so affected. (c) To avoid any confusion any ‘dewatering’ time which prevents an Employee from being engaged in their normal productive work is not included in any calculation for the purposes of determining whether an Employee is entitled to go home due to wet weather (refer clauses 32.4 and 32.5)
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Cleanliness and Safety; Entry Resident agrees to maintain the assigned bedroom space, the apartment and the common areas of the Property in a clean, safe and sanitary condition, to exercise all due care in the use of same, and to cooperate fully with the Property pest control program as requested. Resident will be responsible for the cost of treatment for bedbugs and similar pests to the extent Owner’s pest control vendor reasonably determines that an infestation has originated within Resident’s assigned space and during Resident’s occupancy. Resident will place all trash in provided receptacles and will be responsible for the cost of cleaning the interior or exterior of the apartment if not kept in sanitary condition. When outdoor temperatures are below 40 degrees Fahrenheit, Resident will keep the apartment’s heat turned on to prevent frozen or burst pipes, including during vacations. When outdoor temperatures exceed 85 degrees Fahrenheit, Resident will keep the apartment’s air conditioning turned on and set to a reasonable temperature to prevent mold or mildew growth, including during vacations. Owner and its agents, employees and contractors may enter any apartment and bedroom space to perform routine maintenance, inspections, showings and other ordinary functions, provided that Owner will provide advance notice to residents of an apartment before such entry. Owner reserves the right to enter an apartment and any bedroom space without prior notice (including a passkey and/or disarming the alarm or other means of entry if locks have been changed) for emergency maintenance or repair purposes, or when there is reasonable cause to believe that a situation exists that could cause danger to life, safety, health or property. Owner may confiscate any item deemed to cause a danger and is under no obligation to pay compensation for or to return such items.
Green Economy/Carbon Footprint a) The Supplier/Service Provider has in its bid provided Transnet with an understanding of the Supplier’s/Service Provider’s position with regard to issues such as waste disposal, recycling and energy conservation.
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
Skidding and Yarding Methods of skid- ding or yarding specified for particular areas, if any, are indicated on Sale Area Map. Outside Clearcutting Units and construction clearings, insofar as ground conditions permit, products shall not be skidded against reserve trees or groups of reproduction and tractors shall be equipped with a winch to facilitate skidding. B6.421 Rigging. Insofar as practicable, needed rigging shall be slung on stumps or trees desig- nated for cutting.
Cloud Computing State Risk and Authorization Management Program In accordance with Senate Bill 475, Acts 2021, 87th Leg., R.S., pursuant to Texas Government Code, Section 2054.0593, Contractor acknowledges and agrees that, if providing cloud computing services for System Agency, Contractor must comply with the requirements of the state risk and authorization management program and that System Agency may not enter or renew a contract with Contractor to purchase cloud computing services for the agency that are subject to the state risk and authorization management program unless Contractor demonstrates compliance with program requirements. If providing cloud computing services for System Agency that are subject to the state risk and authorization management program, Contractor certifies it will maintain program compliance and certification throughout the term of the Contract.
