SAFETY OF PERSONS AND PROPERTY 10.2.1 The Contractor shall take all reasonable precautions for the safety of, and shall provide all reasonable protection to prevent damage, injury or loss to: (a) all employees on the Work and all other persons who may be affected thereby; (b) all the Work and all materials and equipment to be incorporated therein, whether in storage on or off-the site, under the care; custody or control of the Contractor or any of his Subcontractors or Sub-subcontractors; and (c) other property at the site or adjacent thereto, including trees, shrubs; lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. 10.2.2 The Contractor shall give all notices and comply with all applicable laws, ordinances, rules, regulations and lawful orders of any public authority bearing on the safety of persons or property or their protection from damage, injury or loss. 10.2.3 The Contractor shall erect and maintain, as required by existing conditions and progress of the Work, all reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent utilities. 10.2.4 When the use or storage of explosives or other hazardous materials or equipment is necessary for the execution of the Work, the Contractor shall: (1) exercise the utmost care and shall carry on such activities under the supervision of properly qualified personnel; and (2) give the State notice, in writing, seven (7) days in advance of the planned activity of the Contractor’s intent to store and/ or use explosives or other hazardous materials or equipment on the project site. 10.2.5 When the project involves the placement or replacement of roofing systems of all types on State- owned buildings, including flat, low-pitched and steep roofs, Contractor must comply with all requirements of the latest edition of VOSHA Safety and Health Standards for Construction (29 CFR 1926) including, but not limited to, Subpart M – Fall Protection. Prior to execution of a contract by BGS, contractors engaged in placement or replacement of roofing systems of all types must submit a signed certification statement attesting to their intention to comply with VOSHA Fall Protection Regulations. Such certification shall be submitted on a State-provided form along with proof of insurance. 10.2.6 The Contractor shall promptly remedy all damage or loss (consistent with Contractor’s obligations described in Attachment C) to any property referred to in Clauses 10.2.1(b) and 10.2.1(c) of these General Conditions caused in whole or in part by the Contractor, any 10.2.7 The Contractor shall designate a responsible member of his organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor's superintendent unless otherwise designated by the Contractor in writing to the State and the Architect. 10.2.8 The Contractor shall not load or permit any part of the Work to be loaded so as to endanger its safety.
Contents of Personnel File A. Adverse statements prepared by the County shall not be included in an employee's official personnel file unless a copy is provided to the employee. B. An employee shall have the right to inspect and review the contents of his or her official personnel file at reasonable intervals. C. In addition, an employee shall have the right to inspect and review the contents of his or her official personnel file in any case where the employee has a grievance related to performance; to a performance evaluation; or is contesting his or her suspension or discharge from County service. D. Letters of reference and reports concerning criminal investigations concerning the employee shall be excluded from the provisions of B. and C., above. E. An employee shall have the right to respond in writing or personal interview to any information contained in his or her official personnel file, such reply to become a permanent part of such employee's official personnel file. F. Any contents of an employee's official personnel file may be destroyed pursuant to an agreement between the Chief of Employee Relations and the employee concerned or by an order of an arbitrator, court or impartial hearing officer unless the particular item is otherwise required by law to be kept.
Protection of Persons and Property The AGENCY shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the performance of this Contract. a. The AGENCY shall take all reasonable precautions for the safety and protection of: i. All employees and all persons whom the AGENCY suffers to be on the premises and other persons who may be affected thereby; ii. All property, materials, and equipment on the premises under the care, custody or control of the AGENCY; and iii. Other property at or surrounding the premises. b. The AGENCY agrees that the COUNTY does not guarantee the security of any equipment or personal property brought by the AGENCY, its agents or employees onto the COUNTY property and that the COUNTY shall in no way be liable for damage, destruction, theft or loss of any equipment and appurtenances regardless of the reason for such damage, destruction, theft or loss. c. The AGENCY shall comply with, and shall ensure that its contractors comply with, all applicable safety laws or ordinances, rules, regulations, standards and lawful orders from authority bearing on the safety of persons or property for their protection from damage, injury or loss. This includes, but is not limited to, the following: i. Occupational Safety & Health Act (OSHA) ii. National Institute for Safety and Health (NIOSH) iii. National Fire Protection Association (NFPA) The AGENCY must also comply with the guidelines set forth in the Orange County Safety & Health Manual. The manual can be accessed online at the address below: d. In any emergency affecting the safety of persons or property, the AGENCY will act with reasonable care and discretion to prevent any threatened damage, injury, or loss.
Standard of Performance Consultant represents and warrants that it has the qualifications, experience and facilities necessary to properly perform the services required under this Agreement in a thorough, competent and professional manner. Consultant shall at all times faithfully, competently and to the best of its ability, experience and talent, perform all services described herein. In meeting its obligations under this Agreement, Consultant shall employ, at a minimum, generally accepted standards and practices utilized by persons engaged in providing services similar to those required of Consultant under this Agreement.
Availability of Personnel The Subadvisor at its expense will make available to the Directors and Advisor at reasonable times its portfolio managers and other appropriate personnel, either in person, or, at the mutual convenience of the Advisor and the Subadvisor, by telephone, in order to review the Fund's investment policies and to consult with the Directors and Advisor regarding the Fund's investment affairs, including economic, statistical and investment matters relevant to the Subadvisor's duties hereunder, and will provide periodic reports to the Advisor relating to the investment strategies it employs.
Continuity of Performance In the event of a dispute between the Party and the State, each party will continue to perform its obligations under this Agreement during the resolution of the dispute until this Agreement is terminated in accordance with its terms.
Failure of Performance (Art. 44)
Impossibility of Performance The credit union will not be liable for failure to comply with the terms of a wire transfer agreement caused by legal constraint interruption or failure of transmission and/or communications facilities, war, emergency, labor dispute, act of nature, or other circumstances beyond the control of the credit union.
Excuse of Performance Seller shall not be liable for delays in performance or for non-performance due to failure or interruption of computer or telecommunication systems, acts of God, war, riot, fire, terrorism, labor trouble, unavailability of materials or components, explosion, accident, compliance with governmental requests, laws, regulations, orders or actions, or other unforeseen circumstances or causes beyond Seller's reasonable control. In the event of such delay, the time for performance or delivery shall be extended by a period of time reasonably necessary to overcome the effect of the delay.
Review of Personnel File Upon written authority from an employee, OC shall permit the President of the Union or their designate to review that employee's personnel file in the office in which the file is normally kept in order to facilitate the proper investigation of a grievance.