Time of Performance means the specific time or times indicated in the Contract at which or within which delivery or other performance is to be completed.
Standard of performance means a standard for emission of air pollutants which reflects the degree of emission limitation achievable through the application of the best system of emission reduction which (taking into account the cost of achieving such reduction) the Director determines has been adequately demonstrated.
Schedule of Performance means that schedule of performance, attached hereto as Exhibit G and incorporated herein, setting forth the timelines for Milestones in the design, development, construction, and completion of the Project (including a construction timeline in customary form) together with the dates for submission of documentation required under this Agreement, which schedule shall be attached to the Development Plan and to the Declaration.
Adequate Assurance of Performance has the meaning given to it in Section 10.3.
human performance means human capabilities and limitations which have an impact on the safety and efficiency of aeronautical operations;
Unsatisfactory Performance means any of the following:
Basket Performance means a decimal number calculated by applying the following formula: BP = ∑ W ×iX ⎛⎜⎜i=1 ⎝ Underlyingi,FINAL ⎞⎟⎠Underlyingi,INITIAL ⎟ where: BP = Basket Performance X = 4 Wi = Weighting of the relevant Underlying Underlying i,FINAL Underlying i,INITIAL= Reference Price of the relevant Underlying with respect to the Valuation Date = Initial Price of the relevant Underlying
Index Performance means, in relation to an Index and an Auto-Call Valuation Date or the Valuation Date, as the case may be, a percentage calculated by the Calculation Agent in respect of such date in accordance with the following formula: Index Performance =Final Index Level × 100% Initial Index Level
Sexually explicit performance means a live or public act or show intended to arouse or satisfy the sexual desires or appeal to the prurient interest of patrons.
Obscene matter or an obscene performance means matter described in 1984 PA 343, MCL 752.361 to 752.374.
Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.
Total Performance means that the entire Work, except those items arising from the provisions of any warranty, have been performed in accordance with the Contract;
Publicly Perform means to perform public recitations of the Work and to communicate to the public those public recitations, by any means or process, including by wire or wireless means or public digital performances; to make available to the public Works in such a way that members of the public may access these Works from a place and at a place individually chosen by them; to perform the Work to the public by any means or process and the communication to the public of the performances of the Work, including by public digital performance; to broadcast and rebroadcast the Work by any means including signs, sounds or images.
Performance has the meaning ascribed to it in the Copyright Act 98 of 1978, as amended from time to time, and the words “Perform” and “Performed” and
Enforced disappearance of persons means the arrest, detention or abduction of persons by, or with the authorization, support or acquiescence of, a State or a political organization, followed by a refusal to acknowledge that deprivation of freedom or to give information on the fate or whereabouts of those persons, with the intention of removing them from the protection of the law for a prolonged period of time.
Environmental Performance means all or any of the following: the consumption of energy and associated generation of greenhouse gas emissions; the consumption of water; waste generation and management; and any other environmental impact arising from the use or operation of the Premises or the Estate;
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Milestone Failure means a failure by the Grant Recipient fully to achieve any Milestone by the relevant Milestone Date;
Substantial Performance means the stage of completion when:(a) all Work, as certified by the Contract Administrator, is capable of completion or correction at a cost of not more than:
Performance Failure shall have the meaning as set forth in Section 2.03(b)(i)(1).
Data Breaches Party shall report to AHS, though its Chief Information Officer (CIO), any impermissible use or disclosure that compromises the security, confidentiality or privacy of any form of protected personal information identified above within 24 hours of the discovery of the breach. Party shall in addition comply with any other data breach notification requirements required under federal or state law.
Data Breach means the unauthorized access by an unauthorized person that results in the use, disclosure or theft of Customer Data.
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Extreme performance coating means coatings designed for harsh exposure or extreme environmental conditions.
Specified Agreement is defined in Section 8.1(e) of the Agreement.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.