CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Reporting Total Compensation of Recipient Executives 1. Applicability and what to report. You must report total compensation for each of your five most highly compensated executives for the preceding completed fiscal year, if—
i. the total Federal funding authorized to date under this award is $25,000 or more;
ii. in the preceding fiscal year, you received—
(a) 80 percent or more of your annual gross revenues from Federal procurement contracts (and subcontracts) and Federal financial assistance subject to the Transparency Act, as defined at 2 CFR 170.320 (and subawards); and
(b) $25,000,000 or more in annual gross revenues from Federal procurement contracts (and subcontracts) and Federal financial assistance subject to the Transparency Act, as defined at 2 CFR 170.320 (and subawards); and
iii. The public does not have access to information about the compensation of the executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986. (To determine if the public has access to the compensation information, see the U.S. Security and Exchange Commission total compensation filings at xxxx://xxx.xxx.xxx/answers/execomp.htm.)
2. Where and when to report. You must report executive total compensation described in paragraph A.1. of this award term:
i. As part of your registration profile at xxxxx://xxx.xxx.gov.
ii. By the end of the month following the month in which this award is made, and annually thereafter.
Contractor’s Performance Warranties Contractor represents and warrants to the State that:
(i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment.
(ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure.
(iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
Compensation for Damages 4.1 If the Principal has disqualified the Bidder from the tender process prior to the award according to Section 3, the Principal is entitled to demand and recover the damages equivalent Xxxxxxx Money Deposit/Bid Security.
4.2 If the Principal has terminated the contract according to Section 3, or if the Principal is entitled to terminate the contract according to section 3, the Principal shall be entitled to demand and recover from the Contractor liquidated damages equivalent to 5% of the contract value or the amount equivalent to Security Deposit/Performance Bank Guarantee, whichever is higher.
Performance of Service; Limitation of Liability A. PFS shall exercise reasonable care in the performance of its duties under this Agreement. PFS shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with matters to which this Agreement relates, including losses resulting from mechanical breakdowns or the failure of communication or power supplies beyond PFS's control, except a loss arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence, or willful misconduct on its part in the performance of its duties under this Agreement. Notwithstanding any other provision of this Agreement, if PFS has exercised reasonable care in the performance of its duties under this Agreement, the Trust shall indemnify and hold harmless PFS from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which PFS may sustain or incur or which may be asserted against PFS by any person arising out of any action taken or omitted to be taken by it in performing the services hereunder, except for any and all claims, demands, losses, expenses, and liabilities arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence or from willful misconduct on its part in performance of its duties under this Agreement, (i) in accordance with the foregoing standards, or (ii) in reliance upon any written or oral instruction provided to PFS by any duly authorized officer of the Trust, such duly authorized officer to be included in a list of authorized officers furnished to PFS and as amended from time to time in writing by resolution of the Board of Trustees of the Trust. PFS shall indemnify and hold the Trust harmless from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which the Trust may sustain or incur or which may be asserted against the Trust by any person arising out of any action taken or omitted to be taken by PFS as a result of PFS's refusal or failure to comply with the terms of this Agreement, its bad faith, negligence, or willful misconduct. In the event of a mechanical breakdown or failure of communication or power supplies beyond its control, PFS shall take all reasonable steps to minimize service interruptions for any period that such interruption continues beyond PFS's control. PFS will make every reasonable effort to restore any lost or damaged data and correct any errors resulting from such a breakdown at the expense of PFS. PFS agrees that it shall, at all times, have reasonable contingency plans with appropriate parties, making reasonable provision for emergency use of electrical data processing equipment to the extent appropriate equipment is available. Representatives of the Trust shall be entitled to inspect PFS's premises and operating capabilities at any time during regular business hours of PFS, upon reasonable notice to PFS.
B. In order that the indemnification provisions contained in this section shall apply, it is understood that if in any case the indemnitor may be asked to indemnify or hold the indemnitee harmless, the indemnitor shall be fully and promptly advised of all pertinent facts concerning the situation in question, and it is further understood that the indemnitee will use all reasonable care to notify the indemnitor promptly concerning any situation which presents or appears likely to present the probability of a claim for indemnification. The indemnitor shall have the option to defend the indemnitee against any claim which may be the subject of this indemnification. In the event that the indemnitor so elects, it will so notify the indemnitee and thereupon the indemnitor shall take over complete defense of the claim, and the indemnitee shall in such situation initiate no further legal or other expenses for which it shall seek indemnification under this section. The indemnitee shall in no case confess any claim or make any compromise in any case in which the indemnitor will be asked to indemnify the indemnitee except with the indemnitor's prior written consent.
C. PFS is hereby expressly put on notice of the limitation of shareholder, Trustee, officer, employee or agent liability as set forth in the Declaration of Trust of the Trust and agrees that obligations assumed by the Trust pursuant to this Agreement shall be limited in all cases to the Trust and its assets, and if the liability relates to one or more Funds, the obligations hereunder shall be limited to the respective assets of such Fund. PFS further agrees that it shall not seek satisfaction of any such obligation from any shareholder of a Fund, nor from any Trustee, officer, employee or agent of the Trust.
Specific Performance, Etc The parties recognize that if any provision of this Agreement is violated by the Company, Indemnitee may be without an adequate remedy at law. Accordingly, in the event of any such violation, Indemnitee shall be entitled, if Indemnitee so elects, to institute Proceedings, either in law or at equity, to obtain damages, to enforce specific performance, to enjoin such violation, or to obtain any relief or any combination of the foregoing as Indemnitee may elect to pursue.
Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
