Time for Performance The term of this SOW Agreement shall begin on and end on _ (the “Initial Term”). The Initial Term may be extended as the parties may agree. The State may terminate this SOW for convenience upon thirty days prior written notice to the Contractor. If the Master Agreement should expire or otherwise terminate prior to the end of the term of this SOW Agreement, this SOW Agreement shall continue to the end of its existing term, unless or until terminated in accordance with the terms of this SOW Agreement, and the Parties acknowledge and agree that the terms of the Master Agreement shall survive and apply to this SOW Agreement.
Performance of the Work The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project.
CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.
The Performance Improvement Process (a) The Performance Improvement Process will focus on the risks of non- performance and problem-solving. It may include one or more of the following actions: (1) a requirement that the HSP develop and implement an improvement plan that is acceptable to the LHIN; (2) the conduct of a Review; (3) a revision and amendment of the HSP’s obligations; and (4) an in-year, or year end, adjustment to the Funding, among other possible means of responding to the Performance Factor or improving performance. (b) Any performance improvement process begun under a prior service accountability agreement that was not completed under the prior agreement will continue under this Agreement. Any performance improvement required by a LHIN under a prior service accountability agreement will be deemed to be a requirement of this Agreement until fulfilled or waived by the LHIN.
SCHEDULE FOR PERFORMANCE REVIEWS 7.1 The performance of the Employee in relation to his performance agreement shall be reviewed for the following quarters with the understanding that the reviews in the first and the third quarter may be verbal if performance is satisfactory:
Scope of the Project Under this Agreement, the scope of the Project (the “Scope of the Project”) shall mean and include: (a) construction of the Project Highway on the Site set forth in Schedule- A and as specified in Schedule-B together with provision of Project Facilities as specified in Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D; (b) maintenance of the Project Highway in accordance with the provisions of this Agreement and in conformity with the requirements set forth in Schedule-E; and (c) performance and fulfilment of all other obligations of the Contractor in accordance with the provisions of this Agreement and matters incidental thereto or necessary for the performance of any or all of the obligations of the Contractor under this Agreement.
Performance of Reviews The RIRs shall send a request for review to the Operator per email, where they shall specify the areas they request a review for. The Operator must comply with the request by providing the requested information within working days. The review may include an onsite inspection. In this case the RIRs and the Operator must agree on a specific date for the inspection to take place, which may not be later than sixty calendar days from the date of the request.
Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.
Consideration for Performance The consideration to be paid to the Contractor under this Agreement will be compensation for all the Contractor’s expenses incurred in the performance of this Agreement, unless otherwise expressly provided.
PERFORMANCE OF THE CONTRACT II.1.1. The Contractor shall perform the Contract to the highest professional standards. The Contractor shall have sole responsibility for complying with any legal obligations incumbent on him, notably those resulting from employment, tax and social legislation. II.1.2. The Contractor shall have sole responsibility for taking the necessary steps to obtain any permit or licence required for performance of the Contract under the laws and regulations in force at the place where the tasks assigned to him are to be executed. II.1.3. Without prejudice to Article II.3 any reference made to the Contractor’s staff in the Contract shall relate exclusively to individuals involved in the performance of the Contract. II.1.4. The Contractor must ensure that any staff performing the Contract have the professional qualifications and experience required for the execution of the tasks assigned to them. II.1.5. The Contractor shall neither represent the Agency nor behave in any way that would give such an impression. The Contractor shall inform third parties that he does not belong to the European public service. II.1.6. The Contractor shall have sole responsibility for the staff who execute the tasks assigned to him. II.1.7. In the event of disruption resulting from the action of a member of the Contractor's staff working on Agency premises or in the event of the expertise of a member of the Contractor's staff failing to correspond to the profile required by the Contract, the Contractor shall replace him without delay. The Agency shall have the right to request the replacement of any such member of staff, stating its reasons for so doing. Replacement staff must have the necessary qualifications and be capable of performing the Contract under the same contractual conditions. The Contractor shall be responsible for any delay in the execution of the tasks assigned to him resulting from the replacement of staff in accordance with this Article. II.1.8. Should any unforeseen event, action or omission directly or indirectly hamper execution of the tasks, either partially or totally, the Contractor shall immediately and on his own initiative record it and report it to the Agency. The report shall include a description of the problem and an indication of the date on which it started and of the remedial action taken by the Contractor to ensure full compliance with his obligations under the Contract. In such event the Contractor shall give priority to solving the problem rather than determining liability. II.1.9. Should the Contractor fail to perform his obligations under the Contract in accordance with the provisions laid down therein, the Agency may - without prejudice to its right to terminate the Contract - reduce or recover payments in proportion to the scale of the failure. In addition, the Agency may impose penalties or liquidated damages provided for in Article II.16.
