INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Third Party Infringement Claims In the event any claim or action for infringement of any patent, trademark, or other intellectual property right shall be made or brought by a third party against Seller, Purchaser or any of their respective Affiliates because of, or in anticipation of, the manufacture and supply of Product by Seller to Purchaser hereunder, or the marketing, sale or distribution of such Product to Purchaser Customers in the Territory by Purchaser hereunder (a “Third Party Infringement Claim”), the party first receiving such notice of the Third Party Infringement Claim shall promptly notify the other party. With respect to the Third Party Infringement Claim, Seller and Purchaser each hereby agrees that all Damages arising from or related to the Third Party Infringement Claim (including any legal fees and associated costs incurred in defending the Third Party Infringement Claim and any fees, royalties or other amounts paid in settlement or upon judgment) shall be shared as follows:
(a) Except as provided in clause (b) below, Seller shall be 100% responsible for all Damages arising from any Third Party Infringement Claim, including any fees, royalties or other amounts agreed to be paid in settlement or upon judgment of the Lawsuit or otherwise; and
(b) Purchaser shall be 100% responsible for all Damages arising from any Third Party Infringement Claim with respect to the use of Purchaser Trademarks. Each party agrees to indemnify the other party to ensure that Damages arising from any Third Party Infringement Claim are allocated in accordance with clauses (a) and (b) above. Unless otherwise agreed to by the parties, Seller shall control the defense any Third Party Infringement Claim described in clause (a) above and Purchaser shall control the defense of any Third Party Infringement Claim described in clause (b) above. The party controlling the defense of any Third Party Infringement Claim shall have the sole right to defend or settle any such Third Party Infringement Claim; provided, however, that such settlement does not impose any obligation or burden on the other party without the prior written consent of the other party (which consent shall not be unreasonably withheld). The party controlling the defense of any Third Party Infringement Claim shall keep the other party, at its request, materially informed of the status and progress of the defense of the Third Party Infringement Claim. No Third Party Infringement Claim shall be settled by the party who is not controlling the defense of such Third Party Infringement Claim without the prior written consent of the party controlling such defense. The non-controlling party, its employees, agents and Affiliates shall reasonably cooperate with the party (and its legal representatives) controlling the defense of any Third Party Infringement Claim in the investigation and defense of such Third Party Infringement Claim. Notwithstanding the above, and by way of clarification, neither party shall be obligated to indemnify the other party hereunder for modification or misuse of the Product by the other party or by wholesalers or the customers of either party. The provisions of this Section 17.4 shall be notwithstanding any conflicting provisions set forth in this Agreement, including Sections 17.1, 17.2 and 17.3.
Determination That Indemnification Is Proper Any indemnification hereunder shall (unless otherwise ordered by a court) be made by the Corporation unless a determination is made that indemnification of such person is not proper in the circumstances because he or she has not met the applicable standard of conduct set forth in Section 1(b) hereof. Any such determination shall be made (i) by a majority vote of the directors who are not parties to the action, suit or proceeding in question (“disinterested directors”), even if less than a quorum, (ii) by a majority vote of a committee of disinterested directors designated by majority vote of disinterested directors, even if less than a quorum, (iii) by a majority vote of a quorum of the outstanding shares of stock of all classes entitled to vote on the matter, voting as a single class, which quorum shall consist of stockholders who are not at that time parties to the action, suit or proceeding in question, (iv) by independent legal counsel, or (v) by a court of competent jurisdiction.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Claimed Infringement Each Party will promptly notify the other Party if a Third Party brings any Action alleging patent infringement by Lian or Landos or any of their respective Affiliates or Sublicensees with respect to the Development, Manufacture or Commercialization of any Licensed Product or Joint Patent Rights (any such Action, an “Infringement Claim”) in the Territory. Lian will have the right, but not the obligation, to control the defense and response to any such Infringement Claim in the Territory with respect to Lian’s activities, at Lian’s sole cost and expense, and Landos will have the right, at its own expense, to be represented in any such Infringement Claim in the Territory by counsel of its own choice. Landos will have the sole right, but not the obligation, to control the defense and response to any such Infringement Claim with respect to Landos’ activities, including any such Infringement Claim in the Territory or outside of the Territory. Upon the request of the Party controlling the response to the Infringement Claim, the other Party will reasonably cooperate with the controlling Party in the reasonable defense of such Infringement Claim. The other Party will have the right to consult with the controlling Party concerning any Infringement Claim and to participate in and be represented by independent counsel in any associated litigation. If the Infringement Claim is brought against both Parties, then each Party will have the right to defend against the Infringement Claim. The Party defending an Infringement Claim under this Section 7.4 (Claimed Infringement) will (a) consult with the other Party as to the strategy for the prosecution of such defense, (b) consider in good faith any comments from the other Party with respect thereto and (c) keep the other Party reasonably informed of any material steps taken and provide copies of all material documents filed, in connection with such defense. The Party controlling the defense against an Infringement Claim will have the right to settle such Infringement Claim on terms deemed reasonably appropriate by such Party, provided, that, neither Party will have the right to settle any Infringement Claim under this Section 7.4 (Claimed Infringement) in a manner that diminishes the rights or interests of the other Party under this Agreement without the consent of such other Party, which consent will not be unreasonably withheld.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses.
(b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person.
(c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.
Defense of Infringement Claims In the event Licensee or Licensor becomes aware that Licensee’s or any of its Affiliates’ or any Sublicensees’ practice of the Licensed Patents is the subject of a claim for patent infringement by a Third Party, that Party shall promptly notify the other, and the Parties shall consider the claim and the most appropriate action to take. Licensee shall cause each of its Affiliates and each Sublicensee to notify Licensee promptly in the event such entity becomes aware that its practice of the Licensed Patents is the subject of a claim of patent infringement by another. To the extent Licensor takes any action, Licensor (or the ReGenX Licensors) shall have the right to require Licensee’s reasonable cooperation in any such suit, upon written notice to Licensee; and Licensee shall have the obligation to participate upon Licensor’s request, in which event, Licensor shall bear the cost of Licensee’s participation. Without Licensor’s prior written permission, Licensee must not settle or compromise any such suit in a manner that imposes any material obligations or restrictions on Licensor or the ReGenX Licensors or grants any rights to the Licensed Patents other than rights that Licensee has the right to grant under this Agreement.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Claim Notice A Party that seeks indemnity under this Article X (an “Indemnified Party”) will give written notice (a “Claim Notice”) to the Party from whom indemnification is sought (an “Indemnifying Party”), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the “Claimed Amount”) of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.
