CONTRACT DIRECTION (a) Only the LOCKHEED XXXXXX Procurement Representative has authority on behalf of LOCKHEED XXXXXX to make changes to this Contract. All amendments must be identified as such in writing and executed by the parties. (b) LOCKHEED XXXXXX engineering and technical personnel may from time to time render assistance or give technical advice or discuss or effect an exchange of information with SELLER's personnel concerning the Work hereunder. No such action shall be deemed to be a change under the "Changes" clause of this Contract and shall not be the basis for equitable adjustment. (c) Except as otherwise provided herein, all notices to be furnished by SELLER shall be in writing and sent to the LOCKHEED XXXXXX Procurement Representative.
Appointment of Subservicer or Subcontractor (a) The Servicer may at any time appoint a subservicer to perform all or any portion of its obligations as Servicer hereunder; provided, however, that the Servicer shall remain obligated and be liable to the Issuer, the Owner Trustee, the Delaware Trustee, the Indenture Trustee, the Certificateholders and the Noteholders for the servicing and administering of the Receivables in accordance with the provisions hereof without diminution of such obligation and liability by virtue of the appointment of such subservicer and to the same extent and under the same terms and conditions as if the Servicer alone were servicing and administering the Receivables. The fees and expenses of the subservicer shall be as agreed between the Servicer and its subservicer from time to time, and none of the Issuer, the Owner Trustee, the Delaware Trustee, the Indenture Trustee, the Certificateholders or the Noteholders shall have any responsibility therefor. (b) The Servicer shall cause any Subservicer used by the Servicer (or by any Subservicer) for the benefit of the Issuer to comply with the reporting and compliance provisions of this Agreement to the same extent as if such Subservicer were the Servicer, and to provide the information required with respect to such Subservicer as is required to file all required reports with the Commission. The Servicer shall be responsible for obtaining from each Subservicer and delivering to the Issuer and the Administrator any servicer compliance statement required to be delivered by such Subservicer under Section 3.11, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 3.12 and any certification required to be delivered to the Person that will be responsible for signing the Sarbanes Certification under Section 3.12(a)(iv) as and when required to be delivered. (c) The Servicer shall promptly upon request provide to the Issuer or the Administrator, acting on behalf of the Issuer, a written description (in form and substance satisfactory to the Issuer and the Administrator) of the role and function of each Subcontractor utilized by the Servicer or any Subservicer, specifying (i) the identity of each such Subcontractor, (ii) which, if any, of such Subcontractors are “participating in the servicing function” within the meaning of Item 1122 of Regulation AB, and (iii) which, if any, elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be “participating in the servicing function” within the meaning of Item 1122 of Regulation AB, the Servicer shall cause any such Subcontractor used by the Servicer (or by any Subservicer) for the benefit of the Issuer and the Depositor to comply with the reporting and compliance provisions of Section 3.12(a) of this Agreement to the same extent as if such Subcontractor were the Servicer. The Servicer shall be responsible for obtaining from each Subcontractor and delivering to the Issuer and the Administrator any assessment of compliance and attestation required to be delivered by such Subcontractor, in each case as and when required to be delivered.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.
Limitation of Liability of Owner Trustee and Indenture Trustee (a) Notwithstanding anything contained herein to the contrary, this Agreement has been countersigned by BNY Mellon Trust of Delaware, not in its individual capacity but solely as Owner Trustee and in no event shall BNY Mellon Trust of Delaware have any liability for the representations, warranties, covenants, agreements or other obligations of the Issuing Entity hereunder or in any of the certificates, notices or agreements delivered pursuant hereto, as to all of which recourse shall be had solely to the assets of the Issuing Entity. For all purposes of this Agreement, in the performance of any duties or obligations of the Issuing Entity hereunder, the Owner Trustee shall be subject to, and entitled to the benefits of, the terms and provisions of Article VI of the Trust Agreement. (b) Notwithstanding anything contained herein to the contrary, this Agreement has been countersigned by Deutsche Bank Trust Company Americas, not in its individual capacity but solely in its capacity as Indenture Trustee and in no event shall Deutsche Bank Trust Company Americas have any liability for the representations, warranties, covenants, agreements or other obligations of the Issuing Entity hereunder or in any of the certificates, notices or agreements delivered pursuant hereto, as to all of which recourse shall be had solely to the assets of the Issuing Entity. For all purposes of this Agreement, in the performance of any duties or obligations of the Issuing Entity hereunder, the Indenture Trustee shall be subject to, and entitled to the benefits of, the terms and provisions of Article VI of the Indenture.
Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.
Eligibility Requirements for Owner Trustee and Delaware Trustee The Owner Trustee shall at all times (i) maintain its principal place of business in the State of New York or such other location within the United States to which the Depositor shall consent in writing, (ii) be authorized to exercise corporate trust powers, (iii) have a combined capital and surplus of at least $50,000,000, (iv) be subject to supervision or examination by federal or state authorities and (v) have the Required Rating. If such person shall publish reports of condition at least annually pursuant to law or to the requirements of the aforesaid supervising or examining authority, then for the purpose of this Section, the combined capital and surplus of such person shall be deemed to be its combined capital and surplus as set forth in its most recent report of condition so published. The Delaware Trustee shall at all times be a Person satisfying the provisions of Section 3807(a) of the Statutory Trust Statute. In case at any time the Owner Trustee or the Delaware Trustee, as applicable, shall cease to be eligible in accordance with the provisions of this Section, the Owner Trustee or the Delaware Trustee, as applicable, shall resign immediately in the manner and with the effect specified in Section 10.02.
Office of Supplier Diversity The State of Florida supports its diverse business community by creating opportunities for woman-, veteran-, and minority-owned small business enterprises to participate in procurements and contracts. The Department encourages supplier diversity through certification of woman-, veteran-, and minority-owned small business enterprises and provides advocacy, outreach, and networking through regional business events. For additional information, please contact the Office of Supplier Diversity (OSD) at xxxxxxx@xxx.xxxxxxxxx.xxx.
