Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.
Right to Offset If We make a claim payment to You or on Your behalf in error or You owe Us any money, You must repay the amount You owe Us. Except as otherwise required by law, if We owe You a payment for other claims received, We have the right to subtract any amount You owe Us from any payment We owe You.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Right to Opt Out If you do not wish to agree to arbitrate all Disputes in accordance with the terms and conditions of this section, you must advise us in writing at the following address by either hand delivery or a letter postmarked within thirty (30) days following the date you enter into this Agreement. You may opt-out without affecting your application or cardholder status.
Xxxxxx’s Right to Transfer If all of the Shares proposed in the Notice to be transferred to a given Proposed Transferee are not purchased by the Company and/or its assignee(s) as provided in this Section 5, then the Holder may sell or otherwise transfer such Shares to that Proposed Transferee at the Offered Price or at a higher price, provided that such sale or other transfer is consummated within one hundred and twenty (120) days after the date of the Notice, that any such sale or other transfer is effected in accordance with any applicable securities laws and that the Proposed Transferee agrees in writing that the provisions of this Section 5 shall continue to apply to the Shares in the hands of such Proposed Transferee. If the Shares described in the Notice are not transferred to the Proposed Transferee within such period, a new Notice shall be given to the Company, and the Company and/or its assignees shall again be offered the Right of First Refusal before any Shares held by the Holder may be sold or otherwise transferred.
