Estimated Costs The proposed GMP Change Order shall include separately identified dollar amounts, stated as fixed sums, for Actual Costs as estimated by the Design-Builder for the complete construction of the Project, which amount shall include the all Trade Contract and Subcontract Sums, costs of materials, and any Component Change Order Sums;
Increased cost claims (a) A Finance Party intending to make a claim pursuant to Clause 13.1 (Increased costs) shall notify the Agent of the event giving rise to the claim, following which the Agent shall promptly notify the Borrower.
(b) Each Finance Party shall, as soon as practicable after a demand by the Agent, provide a certificate confirming the amount of its Increased Costs.
Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.
Disallowed Costs The Contractor is responsible for any audit exceptions or disallowed costs incurred by its own organization or that of its Subcontractors.
Increased Costs and Reduced Return (a) If any Lender, any Agent or the L/C Issuer shall have determined that any Change in Law shall (i) subject such Agent, such Lender or the L/C Issuer, or any Person controlling such Agent, such Lender or the L/C Issuer to any tax, duty or other charge with respect to this Agreement or any Loan made by such Agent or such Lender or any Letter of Credit issued by the L/C Issuer, or change the basis of taxation of payments to such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer of any amounts payable hereunder (except for Indemnified Taxes and Excluded Taxes), (ii) impose, modify or deem applicable any reserve, special deposit or similar requirement against any Loan, any Letter of Credit or against assets of or held by, or deposits with or for the account of, or credit extended by, such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer or (iii) impose on such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer any other condition regarding this Agreement or any Loan or Letter of Credit, and the result of any event referred to in clauses (i), (ii) or (iii) above shall be to increase the cost to such Agent, such Lender or the L/C Issuer of making any Loan, issuing, guaranteeing or participating in any Letter of Credit, or agreeing to make any Loan or issue, guaranty or participate in any Letter of Credit, or to reduce any amount received or receivable by such Agent, such Lender or the L/C Issuer hereunder, then, upon demand by such Agent, such Lender or the L/C Issuer, the Borrowers shall pay to such Agent, such Lender or the L/C Issuer such additional amounts as will compensate such Agent, such Lender or the L/C Issuer for such increased costs or reductions in amount; provided, however, that notwithstanding anything to the contrary in this Section 2.10(a), it shall be a condition to a Lender’s or L/C Issuer’s exercise of its rights, if any, under this Section 2.10(a) that such Lender or L/C Issuer shall generally be exercising similar rights with respect to borrowers under similar agreements.
(b) If any Agent, any Lender or the L/C Issuer shall have determined that any Change in Law either (i) affects or would affect the amount of capital required or expected to be maintained by such Agent, such Lender or the L/C Issuer or any Person controlling such Agent, such Lender or the L/C Issuer, and such Agent, such Lender or the L/C Issuer determines that the amount of such capital is increased as a direct or indirect consequence of any Loans made or maintained, Letters of Credit issued or any guaranty or participation with respect thereto, such Agent’s, such Lender’s or the L/C Issuer’s or such other controlling Person’s other obligations hereunder, or (ii) has or would have the effect of reducing the rate of return on such Agent’s, such Lender’s or the L/C Issuer’s such other controlling Person’s capital to a level below that which such Agent, such Lender or the L/C Issuer or such controlling Person could have achieved but for such circumstances as a consequence of any Loans made or maintained, Letters of Credit issued, or any guaranty or participation with respect thereto or any agreement to make Loans, to issue Letters of Credit or such Agent’s, such Lender’s or the L/C Issuer’s or such other controlling Person’s other obligations hereunder (in each case, taking into consideration, such Agent’s, such Lender’s or the L/C Issuer’s or such other controlling Person’s policies with respect to capital adequacy), then, upon demand by such Agent, such Lender or the L/C Issuer, the Borrowers shall pay to such Agent, such Lender or the L/C Issuer from time to time such additional amounts as will compensate such Agent, such Lender or the L/C Issuer for such cost of maintaining such increased capital or such reduction in the rate of return on such Agent’s, such Lender’s or the L/C Issuer’s or such other controlling Person’s capital; provided, however, that notwithstanding anything to the contrary in this Section 2.10(b), it shall be a condition to a Lender’s or L/C Issuer’s exercise of its rights, if any, under this Section 2.10(b) that such Lender or L/C Issuer shall generally be exercising similar rights with respect to borrowers under similar agreements.
(c) All amounts payable under this Section 2.10 shall bear interest from the date that is ten (10) days after the date of demand by any Agent, any Lender or the L/C Issuer until Payment in Full to such Agent, such Lender or the L/C Issuer at the Reference Rate. A certificate of such Agent, such Lender or the L/C Issuer claiming compensation under this Section 2.10, specifying the event herein above described and the nature of such event shall be submitted by such Agent, such Lender or the L/C Issuer to the Administrative Borrower, setting forth the additional amount due and an explanation of the calculation thereof, and such Agent’s, such Lender’s or the L/C Issuer’s reasons for invoking the provisions of this Section 2.10, and shall be final and conclusive absent manifest error.
(d) Failure or delay on the part of any Lender to demand compensation pursuant to the foregoing provisions of this Section 2.10 shall not constitute a waiver of such Lender’s right to demand such compensation; provided, that the Borrowers shall not be required to compensate such Agent, such Lender or the L/C Issuer pursuant to this Section 2.10 for any increased costs incurred or reductions suffered more than 180 days prior to the date that such Agent, Lender or L/C Issuer, as the case may be, notifies the Administrative Borrower of the Change in Law giving rise to such increased costs or reductions, and of such Agent’s, Lender’s or L/C Issuer’s intention to claim compensation therefor (except that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180 days period referred to above shall be extended to include the period of retroactive effect thereof).
(e) The obligations of the Loan Parties under this Section 2.10 shall survive the termination of this Agreement and the payment of the Loans and all other amounts payable hereunder.
Direct Costs The Contractor shall separately identify each item of deleted and added work associated with the change or other condition giving rise to entitlement to an equitable adjustment, including increases or decreases to unchanged work impacted by the change. For each item of work so identified, the Contractor shall propose for itself and, if applicable, its first two tiers of subcontractors, the following direct costs:
(1) Material cost broken down by trade, supplier, material description, quantity of material units, and unit cost (including all manufacturing burden associated with material fabrication and cost of delivery to site, unless separately itemized);
(2) Labor cost broken down by trade, employer, occupation, quantity of labor hours, and burdened hourly labor rate, together with itemization of applied labor burdens (exclusive of employer’s overhead, profit, and any labor cost burdens carried in employer’s overhead rate);
(3) Cost of equipment required to perform the work, identified with material to be placed or operation to be performed;
(4) Cost of preparation and/or revision to shop drawings and other submittals with detail set forth in paragraphs (e)(1) and (e)(2) of this clause;
(5) Delivery costs, if not included in material unit costs;
(6) Time-related costs not separately identified as direct costs, and not included in the Contractor’s or subcontractors’ overhead rates, as specified in paragraph
Unallowable Costs Costs that are unallowable under other sections of these principles shall not be allowable under this section solely on the basis that they constitute personnel compensation.
Excess Costs If the Permitted Costs exceeds the Finish Allowance, then Tenant shall pay all such excess costs (“Excess Costs”), provided, however, Landlord will, prior to the commencement of construction of Tenant’s Improvements, advise Tenant of the sum of the Contract Sum and the Construction Management Fee (the “Cost Estimate”). Tenant shall have five (5) business days from and after the receipt of such advice within which to approve or disapprove the Contract Sum and Cost Estimate. If Tenant fails to approve same by the expiration of the fifth such business day, then Tenant shall be deemed to have approved the Proposed Contract Sum and Cost Estimate. If Tenant disapproves the Contract Sum and Cost Estimate within such five (5) business day period, then Tenant shall either reduce the scope of Tenant’s Improvements such that the Contract Sum and Construction Management Fee do not exceed the Finish Allowance or, at Tenant’s option, Landlord shall obtain two (2) additional bids, provided that each day beyond such five (5) business day period and until the rebid is accepted by Tenant shall constitute a Tenant Delay hereunder. The foregoing process shall continue until a Contract Sum and Cost Estimate are accepted or deemed accepted by Tenant. Landlord and Tenant must approve (or be deemed to have approved) the Contract Sum for the construction of Tenant’s Improvements in writing prior to the commencement of construction.
Estimated Cost Estimated costs by construction phases for Specified Roads listed in A7 are stated by segments in the Schedule of Items. Such estimated costs are subject to adjustment under B3.3, B5.2, B5.21, B5.212, B5.25, and B5.26. Appropriately adjusted costs shall be made a part of a revised Schedule of Items and shown as adjustments to Timber Sale Account. The revised Schedule of Items shall supersede any prior Schedule of Items when it is dated and signed by Contracting Officer and a copy is furnished to Purchaser.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
