Epidemic Failure “Epidemic Failure” for any particular Product shall mean a failure resulting from defects in material, workmanship, and manufacturing process, including but not limited to the use of Components with known defects. The Epidemic Failure clause shall be invoked [***]. The failure rate may be calculated [***], as determined by BUYER. Epidemic failures do not supersede the requirements of any expressed or implied warranty defined herein. In the case of an epidemic failure, SUPPLIER’s obligation is to propose an action plan to fix the failure of any affected Product within seventy-two (72) hours of discovery. SUPPLIER shall implement this action plan upon BUYER’s acceptance thereof. If the action plan is not acceptable to BUYER, BUYER can require SUPPLIER to repair or replace, at BUYER’s option, the affected Product. In addition to bearing the costs associated therewith, if requested by BUYER, SUPPLIER shall support and provide at SUPPLIER’s expense a sufficient number of units of the Product to permit the field exchange or “hot swap” of Products at customer sites. The parties agree to make all reasonable efforts to complete the repair or replacement of all affected Products within eight (8) Business Days after written notice of epidemic failure by BUYER to SUPPLIER. SUPPLIER also agrees that BUYER will be supported with accelerated shipments of replacement Product to cover BUYER’s supply requirements. If an Epidemic Failure is caused by (i) a design, including a BUYER-provided test process, as required by the Specifications or (ii) a failure by a Component required by the Specifications, (iii) misuse or damage during transit or damage by a third party at no fault of SUPPLIER, SUPPLIER shall perform the obligations in this Section 10.5 and BUYER shall pay to SUPPLIER the fees mutually agreed upon by the parties in writing. If an Epidemic Failure is caused by any other reason other than as set forth in the immediately preceding sentence, SUPPLIER shall perform the obligations set forth in this Section free of charge. Confidential treatment is being requested for portions of this document. This copy of the document filed as an exhibit omits the confidential information subject to the confidentiality request. Omissions are designated by the symbol [***]. A complete version of this document has been filed separately with the Securities and Exchange Commission.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Local Circuit Switching Capability, including Tandem Switching Capability 4.1.3.1 Definition 4.1.3.2 Notwithstanding BellSouth’s general duty to unbundle local circuit switching, BellSouth shall not be required to unbundle local circuit switching for <<customer_name>> when <<customer_name>> serves end-users with four (4) or more voice-grade (DS-0) equivalents or lines in locations served by BellSouth’s local circuit switches, which are in the following MSAs: Atlanta, GA; Miami, FL; Orlando, FL; Ft. Lauderdale, FL; Charlotte-Gastonia-Rock Hill, NC; Greensboro-Winston Salem-High Point, NC; Nashville, TN; and New Orleans, LA, and BellSouth has provided non-discriminatory cost based access to the Enhanced Extended Link (EEL) throughout Density Zone 1 as determined by NECA Tariff No. 4 as in effect on January 1, 1999. 4.1.3.3 In the event that <<customer_name>> orders local circuit switching for a single end user account name at a single physical end user location with four (4) or more 2-wire voice-grade loops from a BellSouth central office in an MSA listed above, BellSouth shall charge <<customer_name>> the market based rate in Exhibit C for use of the local circuit switching functionality for the affected facilities. 4.1.3.4 A featureless port is one that has a line port, switching facilities, and an interoffice port. A featured port is a port that includes all features then capable or a number of then capable features specifically requested by <<customer_name>>. Any features that are not currently then capable but are technically feasible through the switch can be requested through the NBR/BFR process. 4.1.3.5 BellSouth will provide to <<customer_name>> customized routing of calls: (i) to a requested directory assistance services platform; (ii) to an operator services platform pursuant to Section 10 of Attachment 2; (iii) for <<customer_name>>’s PIC’ed toll traffic in a two (2) PIC environment to an alternative OS/DA platform designated by <<customer_name>>. <<customer_name>> customers may use the same dialing arrangements as BellSouth customers. 4.1.3.6 Remote Switching Module functionality is included in Switching Capability. The switching capabilities used will be based on the line side features they support. 4.1.3.7 Switching Capability will also be capable of routing local, intraLATA, interLATA, and calls to international customer’s preferred carrier; call features (e.g. call forwarding) and Centrex capabilities. 4.1.3.8 Where required to do so in order to comply with an effective Commission order, BellSouth will provide to <<customer_name>> purchasing local BellSouth switching and reselling BellSouth local exchange service under Attachment 1, selective routing of calls to a requested directory assistance services platform or operator services platform. <<customer_name>> customers may use the same dialing arrangements as BellSouth customers, but obtain a <<customer_name>> branded service.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Payment Failure Any Credit Party (i) fails to pay any principal when due under this Agreement or (ii) fails to pay, within three Business Days of when due, any other amount due under this Agreement or any other Credit Document, including payments of interest, fees, reimbursements, and indemnifications;
Hardware Warranty Company warrants that for a period of one (1) year from delivery of Hardware, Hardware will be free from defects in material and workmanship in normal use, but does not cover any of the following: (i) improper installation, maintenance, adjustment, repair or modification by Customer or a third party; (ii) misuse, neglect, or any other cause other than ordinary use, including without limitation, accidents or acts of God; (iii) improper environment, excessive or inadequate heating or air conditioning, electrical power failures, surges, water damage or other irregularities; (iv) third party software or software drivers; or (v) damage during shipment.
