Notification of Government Investigation or Legal Proceeding Provider shall notify OIG, in writing, of any ongoing investigation or legal proceeding by a governmental entity or its agents involving an allegation that Provider has committed a crime or has engaged in fraudulent activities, within 30 days of Provider receiving notice of such investigation or legal proceeding. This notification shall include a description of the allegation(s), the identity of the investigating or prosecuting agency, and the status of such investigation or legal proceeding. Within 30 days after resolution of the matter, Provider shall notify OIG, in writing, of the resolution of the investigation or legal proceeding.
Corporate Examinations and Investigations Prior to the Closing Date, the parties acknowledge that they have been entitled, through their employees and representatives, to make such investigation of the assets, properties, business and operations, books, records and financial condition of the other as they each may reasonably require. No investigations, by a party hereto shall, however, diminish or waive any of the representations, warranties, covenants or agreements of the party under this Agreement.
General Authority of the Collateral Agent By acceptance of the benefits of this Agreement and any other Collateral Documents, each Secured Party (whether or not a signatory hereto) shall be deemed irrevocably (a) to consent to the appointment of the Collateral Agent as its agent hereunder and under such other Collateral Documents, (b) to confirm that the Collateral Agent shall have the authority to act as the exclusive agent of such Secured Party for the enforcement of any provisions of this Agreement and such other Collateral Documents against any Grantor, the exercise of remedies hereunder or thereunder and the giving or withholding of any consent or approval hereunder or thereunder relating to any Collateral or any Grantor’s obligations with respect thereto, (c) to agree that it shall not take any action to enforce any provisions of this Agreement or any other Collateral Document against any Grantor, to exercise any remedy hereunder or thereunder or to give any consents or approvals hereunder or thereunder except as expressly provided in this Agreement or any other Collateral Document and (d) to agree to be bound by the terms of this Agreement and any other Collateral Documents.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
COMPLIANCE WITH NEW YORK STATE INFORMATION SECURITY BREACH AND NOTIFICATION ACT Contractor shall comply with the provisions of the New York State Information Security Breach and Notification Act (General Business Law Section 899-aa; State Technology Law Section 208).
Notice to Taxing Authorities and Insurance Companies The Seller shall transmit to the applicable taxing authorities and insurance companies (including primary mortgage insurance policy insurers, if applicable) and/or agents, notification of the transfer of the servicing to the Purchaser, or its designee, and instructions to deliver all notices, tax bills and insurance statements, as the case may be, to the Purchaser from and after the Transfer Date. The Seller shall provide the Purchaser with copies of all such notices within five (5) Business Days following the Transfer Date;
RESPONSIBILITIES OF THE UNIVERSITY The UNIVERSITY shall designate in writing a faculty member to coordinate with a designee of the FIELDWORK SITE.
Opinion of Special Intellectual Property Counsel for the Company On the Closing Date, the Representative shall have received the opinion of Mxxxxx, Xxxxx & Bockius LLP, as special intellectual property counsel for the Company, dated the Closing Date and addressed to the Representative, in a form reasonably acceptable to the Representative.
No Duty of Investigation; Notice in Trust Instruments, Etc No purchaser, lender, transfer agent or other Person dealing with the Trustees or any officer, employee or agent of the Trust or a Series thereof shall be bound to make any inquiry concerning the validity of any transaction purporting to be made by the Trustees or by said officer, employee or agent or be liable for the application of money or property paid, loaned, or delivered to or on the order of the Trustees or of said officer, employee or agent. Every obligation, contract, instrument, certificate, Share, other security of the Trust or a Series thereof or undertaking, and every other act or thing whatsoever executed in connection with the Trust shall be conclusively presumed to have been executed or done by the executors thereof only in their capacity as Trustees under this Declaration or in their capacity as officers, employees or agents of the Trust or a Series thereof. Every written obligation, contract, instrument, certificate, Share, other security of the Trust or a Series thereof or undertaking made or issued by the Trustees may recite that the same is executed or made by them not individually, but as Trustees under the Declaration, and that the obligations of the Trust or a Series thereof under any such instrument are not binding upon any of the Trustees or Shareholders individually, but bind only the Trust Property or the Trust Property of the applicable Series, and may contain any further recital which they may deem appropriate, but the omission of such recital shall not operate to bind the Trustees individually. The Trustees shall at all times maintain insurance for the protection of the Trust Property or the Trust Property of the applicable Series, its Shareholders, Trustees, officers, employees and agents in such amount as the Trustees shall deem adequate to cover possible tort liability, and such other insurance as the Trustees in their sole judgment shall deem advisable.
Opinion of General Counsel of the Company The General Counsel of the Company, shall have furnished to the Representatives, at the request of the Company, a written opinion, dated the Closing Date and addressed to the Underwriters, in form and substance reasonably satisfactory to the Representatives and substantially in the form previously agreed by the parties hereto.
