Termination/Cancellation/Rejection The State specifically reserves the right upon written notice to immediately terminate the contract or any portion thereof at no additional cost to the State, providing, in the opinion of its Commissioner of Buildings and General Services, the products supplied by Contractor are not satisfactory or are not consistent with the terms of this Contract. The State also specifically reserves the right upon written notice, and at no additional cost to the State, to immediately terminate the contract for convenience and/or to immediately reject or cancel any order for convenience at any time prior to shipping notification.
TERMINATION/CANCELLATION Cancellation of orders once placed with or accepted by Seller can be made only with Seller’s consent. Should Buyer, due to good cause, desire to affect the cancellation of an accepted order, Seller will accept such cancellation on the following basis:
(a) For all made-to-order Goods: Buyer shall pay the purchase price in full for all items completed and ready for delivery; Buyer shall pay a percentage of the purchase price on such items as shall not be completed, equivalent to the percentage of completion; and Buyer shall pay in full the cost of all raw materials, consumable materials, manufacturing dies, tools, patterns and fixtures acquired exclusively for the order, and will take ownership and possession of all such items and will be responsible for labor or other documenting expenses incurred in connection therewith.
(b) For all made-to-stock Goods: Buyer shall pay (i) all costs and expenses of placing the cancelled Goods in a saleable condition (restocking charge), (ii) any outgoing and incoming freight charges incurred by Seller in connection with the delivery and return of such Goods, if applicable, and (iii) all reasonable and necessary expenses incurred by Seller directly incident to the order up to the date of cancellation. Invoices covering said costs shall be due and payable immediately upon Seller’s acceptance of cancellation. A stop work order will be deemed a cancellation and the provisions of this paragraph shall apply. If Buyer purchases Goods pursuant to an order for use in a contract with the U.S. Government and the U.S. Government terminates Buyer’s prime contract or a portion thereof for convenience, Buyer shall have the right to terminate only that portion of its contract with Seller which has been terminated by the U.S. Government in its prime contract. In such case, Buyer shall be responsible for those costs set forth above.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract.
19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days.
19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.
ACCEPTANCE/REJECTION/CANCELLATION The County reserves the right to accept or to reject any or all bids and to make the award to that bidder who, in the opinion of the County, will be in the best interest of and/or the most advantageous to the County. The County also reserves the right to reject the bid of any bidder who has previously failed in the proper performance of an award or to deliver on time contracts of a similar nature or who, in the County’s opinion, is not in a position to perform properly under this award. The County reserves the right to inspect all facilities of bidders in order to make a determination as to the foregoing. The County reserves the right to waive any irregularities and technicalities and may, at its discretion, request a re- bid. Award will be made to the lowest responsive and responsible bidder as determined by the County. The County reserves the right, and the Manager, Procurement Division has absolute and sole discretion, to cancel a solicitation at any time prior to approval of the award by the Board of County Commissioners when such approval is required. The decision to cancel a solicitation cannot be the basis for a protest pursuant to the Orange County Code.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Automatic cancellation The Commitment of each Lender will be automatically cancelled at the close of business on the last day of the Availability Period.
Contract Cancellation DCF may cancel this Contract after providing the Contractor with thirty (30) calendar days written notice of the Contractor’s right to cure a failure of the Contractor to perform under the terms of this Contract. The following are examples of contractor failure that would warrant cancellation: • Breaches or defaults an obligation under the Contract as follows: • Fails to follow the sales and use tax certification requirements of s. 77.66 of the Wisconsin Statutes; • Incurs a delinquent Wisconsin tax liability; • Fails to submit a non-discrimination or affirmative action plan as required here in; • Fails to follow the non-discrimination or affirmative action requirements of subch. II, Chapter 111 of the Wisconsin Statutes (Wisconsin’s Fair Employment Law); • Becomes a Federally debarred Contractor; • Is excluded from Federal procurement and non-procurement contracts; • Fails to maintain and keep in force all required insurance, permits and licenses as provided in this Contract; • Fails to maintain the confidentiality of DCF’s information that is considered to be Confidential Information, proprietary, or containing Personally Identifiable Information; • Contractor violates other state laws; or • Contractor performance threatens the health or safety of a State employee or State customer. The Contractor may cancel this Contract after providing DCF one hundred and twenty (120) calendar days’ notice of the State’s right to cure a failure of the State to perform under the terms of this Contract. Upon cancellation of this Contract for any reason, or upon Contract expiration, each party shall be released from all obligations to the other party arising after the date of cancellation or expiration, except for those that by their terms survive such cancellation or expiration.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
