Subcontract Provisions SUBRECIPIENT will include the provisions of Paragraphs X. A- Civil Rights, and X. B-Affirmative Action, in every subcontract or purchase order, specifically or by reference, so that such provisions will be binding upon each of its own subrecipients or subcontractors.
General Contract Provisions Any and all Schedules to this Agreement form a part hereof. No amendment, waiver, discharge or release of this Agreement shall be binding or enforceable unless made in writing signed by all of the parties hereto. Time is and shall remain of the essence under and pursuant to this Agreement; provided that the time for performing or completing any matter under or pursuant to this Agreement may be extended or abridged by an agreement in writing by the parties or their respective solicitors. Failure by any party to strictly enforce any provisions hereof shall not operate as a waiver or limitation of such party's rights hereunder in respect of any subsequent default. If any provision of this Agreement or the application thereof to any person or circumstance is to any extent held or rendered invalid, unenforceable or illegal, same shall be considered separate and severable herefrom and all other provisions of this Agreement shall remain in full force and effect and be binding upon the parties hereof. The headings set forth in this Agreement are inserted for convenience and reference only and shall in no way define or limit the intent or interpretation of any of the provisions hereof. Wherever in this Agreement any subject matter is described as including specifically described persons, things, events or other items, unless expressly stated to the contrary, the word “including” or any other derivation or variation of that word means, as the case may be, “including, without limitation,” or “including, without limiting the generality of the foregoing,” or such derivation or variation thereof as required by the context. This Agreement shall be read and construed with all changes of gender and number of the party or parties referred to in each case as required by the context, and the covenants and agreements of each party shall be deemed to be joint and several where such party is more than one person, firm or corporation. With respect to each party which is a partnership, each person who is presently a partner of such partnership and each person who becomes a partner of such partnership shall be and continue to be jointly and severally liable for all covenants and agreements of such party notwithstanding that any such person subsequently ceases to be a partner of such partnership, subject to and only to the extent of the limited liability of any such person that is a limited partner of such partnership.
CERTIFICATION OF NONSEGREGATED FACILITIES (Applicable to construction contracts exceeding $10,000) The Contractor certifies that it does not maintain or provide for its establishments, and that it does not permit employees to perform their services at any location, under its control, where segregated facilities are maintained. It certifies further that it will not maintain or provide for employees any segregated facilities at any of its establishments, and it will not permit employees to perform their services at any location under its control where segregated facilities are maintained. The Contractor agrees that a breach of this certification is a violation of the equal opportunity clause of this contract. As used in this certification, the term “segregated facilities” means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms, and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation and housing facilities provided for employees which are segregated by explicit directive or are, in fact, segregated on the basis of race, color, religion, or national origin because of habit, local custom, or any other reason. The Contractor further agrees that (except where it has obtained for specific time periods) it will obtain identical certification from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the equal opportunity clause; that it will retain such certifications in its files; and that it will forward the preceding notice to such proposed subcontractors (except where proposed subcontractors have submitted identical certifications for specific time periods).
Contract Provisions The Recipient will ensure that all Contracts are consistent with and incorporate the relevant provisions of the Agreement, including its insurance provisions. More specifically, but without limiting the generality of the foregoing, the Recipient agrees to include provisions in all Contracts to ensure: (a) that proper and accurate accounts and records are kept and maintained as described in the Agreement including, but not limited to, in paragraph A.7.3(a); (b) that all applicable Requirements of Law including, without limitation, labour and human rights legislation, are complied with; and (c) that the Contract secures the respective rights of the Province and Canada, and any authorized representative or independent auditor identified by the Province or Canada, and the Auditor General of Ontario and the Auditor General of Canada to: (i) inspect and audit the terms of any Contract, record or account in respect of the Project; and (ii) have free and timely access to the Project sites and facilities, and any records, documentation or information, as contemplated pursuant to section A.7.5 (Inspection and Removal).
Engineer Payment of Subproviders No later than ten (10) days after receiving payment from the State, the Engineer shall pay all subproviders for work performed under a subcontract authorized hereunder. The State may withhold all payments that have or may become due if the Engineer fails to comply with the ten-day payment requirement. The State may also suspend the work under this contract or any work authorization until subproviders are paid. This requirement also applies to all lower tier subproviders, and this provision must be incorporated into all subcontracts.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Required Contract Provisions Private service provider contracts paid in whole or part with grant funds shall include the following provisions in the contract between the Grantee and the service provider:
Performance and Compliance with Contracts and Credit and Collection Policy The Seller shall (and shall cause the Servicer to), at its expense, timely and fully perform and comply with all material provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and timely and fully comply in all material respects with the applicable Credit and Collection Policies with regard to each Receivable and the related Contract.
Scope of Services and Term Subject to the provisions for early termination as set forth herein, the Contractor agrees that it will perform the Services enumerated in the scope of services attached hereto as Exhibit A and incorporated herein by reference (the “Scope of Services”) for a term of five years (5) beginning , 2023 through , 2028 (the “Term”). The Authority in its sole discretion may extend the Agreement for two (2) additional one-year periods, for a potential maximum term of *** (**) years. The Authority will provide any such renewal notice in writing at least thirty (30) days prior to expiration of the Agreement. The maximum payment for the Term is set forth in Section II(a). All work shall be diligently performed by the Contractor in an economical, expeditious and professional manner.
REFERENCED CONTRACT PROVISIONS 2 Term: March 10, 20109 through June 30, 20110 3 “Period One” means the period from March 10, 2009 through June 30, 2009 4 “Period Two” means the period from July 1, 2009 through June 30, 2010 5 Maximum Obligation: $88,080 6 Period One Maximum Obligation: $ 44,040 7 Period Two Maximum Obligation: 8 TOTAL CONTRACT MAXIMUM OBLIGATION: $132,120 9 Basis for Reimbursement: Fee for Service 10 11 Payment Method: Fee for Service 12 Notices to COUNTY and CONTRACTOR: 14 COUNTY: County of Orange Health Care Agency 15 Contract Development and Management 16 000 Xxxx 0xx Xxxxxx, Xxxxx 000 00 Xxxxx Xxx, XX 00000-0000 18 CONTRACTOR: National Alliance on Mental Illness 19 dba NAMI Orange County 20 0000 X. 00xx Xxxxxx 00 Xxxxx Xxx, XX 00000 22 Coverage Minimum Limits 24 Workers' Compensation Statutory 25 Employer's Liability $1,000,000 26 Sexual Misconduct Insurance $1,000,000 Comprehensive General Liability Insurancewith $1,000,000 combined single limit 27 Comprehensive broad form Property damage and per occurrence including coverage 28 contractual liability $2,000,000 aggregate 29 Automobile Liability Insurance ), $1,000,000 combined single limit Workers' Compensation Statutory 30 coveringfor owned, non-owned, and hired ) vehicles) per occurrence 31 Employer's Liability Insurance $1,000,000 per occurrence Professional Liability Insurance $1,000,000 per claims made or 34 Sexual Misconduct $1,000,000 per occurrence 35 per occurrence 36