Authority of the Asset Manager (a) Except as set forth in Section 2(e) below and in any guidance as may be established from time to time by the managing member of the Series or the Advisory Board, the Asset Manager shall have sole authority and complete discretion over the care, custody, maintenance and management of the Series #TICKER Asset and to take any action that it deems necessary or desirable in connection therewith. The Asset Manager is authorized on behalf of the Series to, among other things:
(i) purchase and maintain insurance coverage for the Series #TICKER Asset for the benefit of the Series;
(ii) engage third party independent contractors for the care, custody, maintenance and management of the #TICKER Asset;
(iii) develop standards for the care and transportation of the Series #TICKER Asset while in and outside of storage, as applicable;
(iv) reasonably make all determinations regarding the calculation of fees, expenses and other amounts relating to the Series #TICKER Asset paid by the Asset Manager hereunder;
(v) deliver invoices to the managing member of the Company for the payment of all fees and expenses incurred by the Series in connection with the maintenance and operation of the Series #TICKER Asset and ensure delivery of payments to third parties for any such services; and
(vi) generally perform any other act necessary to carry out its obligations under this Agreement.
(b) The Asset Manager shall have full responsibility for the maintenance of the Series #TICKER Asset and handling of inspections.
(c) The Asset Manager shall devote such time to its duties under this Agreement as may be deemed reasonably necessary by the Asset Manager in light of the understanding that such duties are expected to be performed only at occasional or irregular intervals.
(d) The Asset Manager may delegate all or any of its duties under this Agreement to any Person who shall perform such delegated duties under the supervision of the Asset Manager on such terms as the Asset Manager shall determine.
(e) Notwithstanding any other provision of this Agreement to the contrary, the Asset Manager shall not have the authority to:
(i) acquire any asset or service for an amount equal to or greater than 1% of the value of the Series #TICKER Asset as of such date, individually, or 3% of the value of the Series #TICKER Asset as of such date, in the aggregate, without the prior consent of the managing member of the Series; or
(ii) sell, transfer or convey the Series #TICKER Asset, provided, however, that the Asset Manager may deliver to the managing member of the Company any offers received by the Asset Manager to purchase the Series #TICKER Asset and any research or analysis prepared by the Asset Manager regarding the potential sale of the Series #TICKER Asset, including market analysis, survey results or information regarding any inquiries received and information regarding potential purchasers.
RUNNING OF THE ACADEMY Teachers and staff
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Liability of the Adviser (a) The Adviser shall have responsibility for the accuracy and completeness (and liability for the lack thereof) of statements in the Fund's Disclosure Documents.
(b) The Adviser shall be liable to the Fund for any loss (including transaction costs) incurred by the Fund as a result of any investment made by the Adviser in contravention of: (i) any investment policy, guideline or restriction set forth in the Registration Statement or as approved by the Board from time to time and provided to the Adviser; or (ii) applicable law, including but not limited to the 1940 Act and the Code (including but not limited to the Fund's failure to satisfy the diversification or source of income requirements of Subchapter M of the Code) (the investments described in this subsection (b) collectively are referred to as "Improper Investments").
(c) The Adviser shall indemnify and hold harmless the Trust, each affiliated person of the Trust within the meaning of Section 2(a)(3) of the 1940 Act, and each person who controls the Trust within the meaning of Section 15 of the 1933 Act (any such person, an "Indemnified Party") against any and all losses, claims, damages, expenses or liabilities (including the reasonable cost of investigating and defending any alleged loss, claim, damage, expense or liability and reasonable counsel fees incurred in connection therewith) to which any such person may become subject under the 1933 Act, the 1934 Act, the 1940 Act or other federal or state statutory law or regulation, at common law or otherwise, insofar as such losses, claims, damages, expenses or liabilities (or actions in respect thereof) arise out of or are based upon: (i) a breach by the Adviser of this Agreement or of the representations and warranties made by the Adviser herein; (ii) any Improper Investment; (iii) any untrue statement or alleged untrue statement of a material fact contained in any Disclosure Document or the omission or alleged omission from a Disclosure Document of a material fact required to be stated therein or necessary to make the statements therein not misleading; or (iv) the Adviser's performance or non-performance of its duties hereunder; provided, however, that nothing herein shall be deemed to protect any Indemnified Party who is a Trustee or officer of the Trust against any liability to the Trust or to its shareholders to which such Indemnified Party would otherwise be subject by reason or willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of such person's office with the Trust.
Outage Authority and Coordination Developer and Connecting Transmission Owner may each, in accordance with NYISO procedures and Good Utility Practice and in coordination with the other Party, remove from service any of its respective Attachment Facilities or System Upgrade Facilities and System Deliverability Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency State, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to schedule such removal on a date and time mutually acceptable to both the Developer and the Connecting Transmission Owner. In all circumstances either Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Party of such removal.
Eligibility of the Asset Representations Reviewer The Asset Representations Reviewer must be a Person who (a) is not Affiliated with the Seller, the Depositor, the Servicer, the Indenture Trustee, the Owner Trustee or any of their Affiliates and (b) was not, and is not Affiliated with a Person that was, engaged by the Seller or any underwriter to perform any due diligence on the Receivables prior to the Closing Date.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Printing of Collective Agreement The Hospital and Union agree that the cost of printing the collective agreements will be shared equally between the parties. The Union will be responsible for having the collective agreements printed in booklet format within sixty (60) days of its signing by both parties.
Servicing Agreement General Summary The Sellers and the Purchasers intend this Agreement to amend and restate that certain “Servicing Agreement,” dated March 23, 2021, for purposes of the Purchase Agreement and wish to set forth herein the terms upon which each Purchaser will, to the fullest extent permitted by applicable Law and the applicable Corporate Trust Contract, and subject to the applicable provisions of this Agreement, assume the responsibility (as agent of the applicable Seller) to supervise, manage, administer and otherwise discharge the duties of the applicable Seller in a Corporate Trust Capacity under (a) any Restricted Appointment and (b) any Excluded Appointment (collectively, the “Serviced Appointments”), and the Purchasers will discharge and perform when due, and indemnify the Sellers for, the Assumed Servicing Liabilities.
Representations and Warranties of the Asset Representations Reviewer The Asset Representations Reviewer hereby makes the following representations and warranties as of the Closing Date:
