PERMANENT ESTABLISHMENT 1. For the purposes of this Agreement, the term "permanent establishment" means a fixed place of business through which the business of an enterprise is wholly or partly carried on.
2. The term "permanent establishment" includes especially:
(a) a place of management;
(b) a branch;
(c) an office;
(d) a factory;
(e) a workshop, and
(f) a mine, an oil or gas well, a quarry or any other place of extraction of natural resources.
3. The term "permanent establishment" also includes:
(a) a building site, a construction, installation or assembly project, or supervisory activities in connection therewith, but only where such site, project or activities last more than 12 months;
(b) the furnishing of services, including consultancy services, by an enterprise of a Contracting State through employees or other personnel in the other Contracting State for a period or periods aggregating more than 120 days within any twelve-month period.
4. Notwithstanding the preceding provisions of this Article, the term "permanent establishment" shall be deemed not to include:
(a) the use of facilities solely for the purpose of storage, display or delivery of goods or merchandise belonging to the enterprise;
(b) the maintenance of a stock of goods or merchandise belonging to the enterprise solely for the purpose of storage, display or delivery;
(c) the maintenance of a stock of goods or merchandise belonging to the enterprise solely for the purpose of processing by another enterprise;
(d) the maintenance of a fixed place of business solely for the purpose of purchasing goods or merchandise or of collecting information, for the enterprise;
(e) the maintenance of a fixed place of business solely for the purpose of carrying on, for the enterprise, any other activity of a preparatory or auxiliary character;
(f) the maintenance of a fixed place of business solely for any combination of activities mentioned in sub-paragraphs (a) to (e), provided that the overall activity of the fixed place of business resulting from this combination is of a preparatory or auxiliary character.
5. Notwithstanding the provisions of paragraphs 1 and 2, where a person -- other than an agent of an independent status to whom paragraph 6 applies -- is acting on behalf of an enterprise and has, and habitually exercises, in a Contracting State an authority to conclude contracts in the name of the enterprise, that enterprise shall be deemed to have a permanent establishment in that State in respect of any activities which that person undertakes for the enterprise, unless the activities of such person are limited to those mentioned in paragraph 4 which, if exercised through a fixed place of business, would not make this fixed place of business a permanent establishment under the provisions of that paragraph.
6. An enterprise shall not be deemed to have a permanent establishment in a Contracting State merely because it carries on business in that State through a broker, general commission agent or any other agent of an independent status, provided that such persons are acting in the ordinary course of their business.
7. The fact that a company which is a resident of a Contracting State controls or is controlled by a company which is a resident of the other Contracting State, or which carries on business in that other State (whether through a permanent establishment or otherwise), shall not of itself constitute either company a permanent establishment of the other.
Establishment of a Free Trade Area The Parties to this Agreement, consistent with Article XXIV of the General Agreement on Tariffs and Trade 1994 (GATT 1994) and Article V of the General Agreement on Trade in Services (GATS), hereby establish a free trade area.
Establishment of Deposit Account The Deposit Account shall be established and maintained pursuant to Section 5.01 of the Sale and Servicing Agreement. The Deposit Account shall be under the sole dominion and control of the Indenture Trustee for the benefit of Noteholders and the Certificateholders, as applicable in accordance with the Sale and Servicing Agreement.
Establishment of the Trust The Depositor does hereby establish, pursuant to the further provisions of this Agreement and the laws of the State of New York, an express trust to be known, for convenience, as “Deutsche Alt-A Securities Mortgage Loan Trust, Series 2006-AR5” and does hereby appoint HSBC Bank USA, National Association as Trustee in accordance with the provisions of this Agreement.
Establishment On and after the Closing Date, the Indenture Trustee will maintain the Bank Accounts established by the Servicer under Section 4.1 of the Sale and Servicing Agreement.
Establishment of Collateral Account The Securities Intermediary hereby confirms that:
(a) the Securities Intermediary has established the Collateral Account;
(b) the Collateral Account is a securities account;
(c) subject to the terms of this Agreement, the Securities Intermediary shall identify in its records the Collateral Agent as the entitlement holder entitled to exercise the rights that comprise any financial asset credited to the Collateral Account;
(d) all property delivered to the Securities Intermediary pursuant to this Agreement, including any Applicable Ownership Interests in the Treasury Portfolio (as specified in clause (i) of the definition thereof) or Treasury Securities and the Permitted Investments, will be credited promptly to the Collateral Account; and
(e) all securities or other property underlying any financial assets credited to the Collateral Account shall be (i) registered in the name of the Purchase Contract Agent and indorsed to the Securities Intermediary or in blank, (ii) registered in the name of the Securities Intermediary or (iii) credited to another securities account maintained in the name of the Securities Intermediary. In no case will any financial asset credited to the Collateral Account be registered in the name of the Purchase Contract Agent (in its capacity as such) or any Holder or specially indorsed to the Purchase Contract Agent (in its capacity as such) or any Holder, unless such financial asset has been further indorsed to the Securities Intermediary or in blank.
Establishment of Service 6.1 After receiving certification as a local exchange company from the appropriate regulatory agency, <<customer_name>> will provide the appropriate BellSouth service center the necessary documentation to enable BellSouth to establish a master account for <<customer_name>>’s resold services. Such documentation shall include the Application for Master Account, proof of authority to provide telecommunications services, an Operating Company Number ("OCN") assigned by the National Exchange Carriers Association ("NECA") and a tax exemption certificate, if applicable. When necessary deposit requirements are met, as described in Section 6.6 below, BellSouth will begin taking orders for the resale of service.
6.2 Service orders will be in a standard format designated by BellSouth.
6.3 <<customer_name>> shall provide to BellSouth a blanket letter of authorization ("LOA") certifying that <<customer_name>> will have End User authorization prior to viewing the End User's customer service record or switching the End User's service. BellSouth will not require End User confirmation prior to establishing service for <<customer_name>>’s End User customer. <<customer_name>> must, however, be able to demonstrate End User authorization upon request.
6.4 BellSouth will accept a request directly from the End User for conversion of the End User's service from <<customer_name>> to BellSouth or will accept a request from another CLEC for conversion of the End User's service from <<customer_name>> to such other CLEC. Upon completion of the conversion BellSouth will notify <<customer_name>> that such conversion has been completed.
6.5 If BellSouth is informed that an unauthorized change in local service to <<customer_name>> has occurred, BellSouth will reestablish service with the appropriate local service provider and will assess <<customer_name>> as the CLEC initiating the alleged unauthorized change, the unauthorized change charge described in FCC Tariff No. 1, Section 13 or applicable state tariff. Appropriate nonrecurring charges, as set forth in Section A4 of the General Subscriber Service Tariff, will also be assessed to <<customer_name>>. In accordance with FCC Slamming Liability Rules, the relevant governmental agency will determine if an unauthorized change has occurred. Resolution of all relevant issues shall be handled directly with the authorized CLEC and <<customer_name>>.
6.6 BellSouth reserves the right to secure the account with a suitable form of security deposit, unless satisfactory credit has already been established.
6.6.1 Such security deposit shall take the form of cash for cash equivalent, an irrevocable Letter of Credit or other forms of security acceptable to BellSouth. Any such security deposit may be held during the continuance of the service as security for the payment of any and all amounts accruing for the service.
6.6.2 If a security deposit is required, such security deposit shall be made prior to the inauguration of service.
6.6.3 Such security deposit shall be two months' estimated billing.
6.6.4 The fact that a security deposit has been made in no way relieves <<customer_name>> from complying with BellSouth's regulations as to advance payments and the prompt payment of bills on presentation nor does it constitute a waiver or modification of the regular practices of BellSouth providing for the discontinuance of service for non-payment of any sums due BellSouth.
6.6.5 BellSouth reserves the right to increase the security deposit requirements when, in its reasonable judgment, changes in <<customer_name>>'s financial status so warrant and/or gross monthly billing has increased beyond the level initially used to determine the security deposit.
6.6.6 In the event service to <<customer_name>> is terminated due to <<customer_name>>'s default on its account, any security deposits held will be applied to <<customer_name>>'s account.
6.6.7 Interest on a cash or cash equivalent security deposit shall accrue and be paid in accordance with the terms in the appropriate BellSouth tariff.
Alignment with Modernization Foundational Programs and Foundational Capabilities The activities and services that the LPHA has agreed to deliver under this Program Element align with Foundational Programs and Foundational Capabilities and the public health accountability metrics (if applicable), as follows (see Oregon’s Public Health Modernization Manual, (xxxx://xxx.xxxxxx.xxx/oha/PH/ABOUT/TASKFORCE/Documents/public_health_modernization_man ual.pdf):
a. Foundational Programs and Capabilities (As specified in Public Health Modernization Manual)
b. The work in this Program Element helps Oregon’s governmental public health system achieve the following Public Health Accountability Metric:
c. The work in this Program Element helps Oregon’s governmental public health system achieve the following Public Health Modernization Process Measure:
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Establishment of Account (a) The Fund hereby appoints the Custodian as the custodian of all Securities and cash at any time delivered to the Custodian to be held under this Agreement. The Custodian hereby accepts such appointment and agrees to establish and maintain one or more accounts for each Series in which the Custodian will hold Securities and cash as provided herein. Such accounts (each, an “Account,” and collectively, the “Accounts”) shall be in the name of the Fund and Series, if any.
(b) The Custodian may from time to time establish on its books and records such sub-accounts within each Account as the Fund and the Custodian may agree upon (each a “Special Account”), and the Custodian shall reflect therein such assets as the Fund may specify in Instructions.
(c) The Custodian may from time to time establish pursuant to a written agreement with and for the benefit of a broker, dealer, future commission merchant or other third party identified in Instructions such accounts on such terms and conditions as the Fund and the Custodian shall agree, and the Custodian shall transfer to such account such Securities and money as the Fund may specify in Instructions.
