Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Representations and Warranties by the Company The Company represents and warrants to each Underwriter as of the date hereof, the Applicable Time, the Closing Time (as defined below) and any Date of Delivery (as defined below), and agrees with each Underwriter, as follows:
INDEMNIFICATION BY THE COMPETITIVE SUPPLIER Competitive Supplier shall indemnify, defend and hold harmless the Town and its officers, employees, officials, consultants, representatives and independent contractors (the “Indemnified Parties”), from and against any and all costs, liabilities, losses, judgments, damages, and expenses (including reasonable attorney’s fees), arising out of third-party claims, demands, causes of action, suits or other proceedings and incurred by, on behalf of or involving the Indemnified Parties to the extent such claims, demands, causes of action, suits or other proceedings arise from or in connection with (i) any material breach by Competitive Supplier of its obligations, covenants, representations or warranties contained in this Agreement, or (ii) Competitive Supplier’s actions or omissions in connection with its performance of this Agreement to the extent that such actions or omissions were negligent or not Commercially Reasonable. Competitive Supplier further agrees, if requested by the Town in writing to do so, to investigate, handle, respond to, and defend any such claim, demand, cause of action, suit or other proceeding at Competitive Supplier’s expense. The indemnification obligation of Competitive Supplier set forth above is in addition to and not in limitation or in lieu of any other rights and remedies available to the Town. This provision shall survive the expiration or earlier termination of this Agreement.
Use by Third Parties You may permit Authorized Third Parties to exercise the Usage Rights on Your behalf, provided that You are responsible for (a) ensuring that such Authorized Third Parties comply with this XXXX and (b) any breach of this XXXX by such Authorized Third Parties.
Termination by the Service Provider 19.1 The Service Provider may by notice determine the employment of the Service Provider under this Agreement if the Service user is in default in respect of any one or more of the following:
Compensation for default by the Concessionaire Subject to the provisions of Clause 35.6, in the event of the Concessionaire being in material default or breach of this Agreement, it shall pay to the Authority by way of compensation, all direct costs suffered or incurred by the Authority as a consequence of such material default or breach, within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no compensation shall be payable under this Clause 35.1 for any material breach or default in respect of which Damages are expressly specified and payable under this Agreement.