Warranty on Items. Supplier also warrants that no part of any Items or Services provided hereunder shall contain any traces of silicone (any of a large class of polymers of R2SiO where R is a hydrocarbon).
Warranty on Items Sample Clauses
Related to Warranty on Items
Warranty of Services Contractor warrants that the services provided conform to the contract requirements, including all descriptions, specifications and attachments made a part of this contract. The Department’s acceptance of services provided by Contractor shall not relieve Contractor from its obligations under this warranty. In addition to its other remedies under this contract, at law, or in equity, the Department may, at Contractor's expense, require prompt correction of any services failing to meet Contractor's warranty herein. Services corrected by Contractor shall be subject to all the provisions of this contract in the manner and to the same extent as services originally furnished.
Exception Items When we review and process your electronic file, we may reject any electronic image that we determine to be ineligible for the service ("Exception Item") including, without limitation, electronic images of items drawn on banks located outside the United States, items drawn on U.S. Banks in foreign currency, electronic images that are illegible (due to poor image quality or otherwise), electronic images of items previously processed, electronic images previously converted to substitute checks, and electronic images with unreadable MICR information. We will notify you of any Exception Items. You agree that if you wish to attempt to deposit any Exception Item to any of your accounts with Credit Union, you will only do so by depositing the original item on which the Exception Item is based. You acknowledge and agree that even if you do not initially identify an electronic image as an Exception Item, the substitute check created by the Credit Union there from may nevertheless be returned to Credit Union because, among other reasons, the electronic image is deemed illegible by a paying bank. Credit Union's failure to identify an Exception Item shall not preclude or limit your obligations to Credit Union.
Warranty Disclaimer EXCEPT FOR THE LIMITED WARRANTIES STATED ABOVE, THE SOLUTIONS AND ALL RELATED SERVICES ARE PROVIDED “AS IS” AND CUSTOMER’S USE OF THEM IS AT ITS OWN RISK. AVEPOINT DOES NOT MAKE, AND HEREBY SPECIFICALLY DISCLAIMS, AND CUSTOMER RELEASES AND WAIVES, ANY AND ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, STATUTORY OR OTHERWISE OR FROM A COURSE OF DEALING, COURSE OF PERFORMANCE, USAGE OR TRADE PRACTICE, INCLUDING BUT NOT LIMITED TO WARRANTIES OF MERCHANTABILITY, TITLE, FITNESS FOR A PARTICULAR PURPOSE OR NONINFRINGEMENT. AVEPOINT DOES NOT WARRANT THAT CUSTOMER’S USE OF THE SOLUTIONS WILL BE UNINTERRUPTED OR ERROR- FREE, NOR DOES AVEPOINT WARRANT THAT IT WILL REVIEW CUSTOMER DATA FOR ACCURACY OR THAT IT WILL PRESERVE OR MAINTAIN CUSTOMER DATA WITHOUT LOSS. AVEPOINT SHALL NOT BE LIABLE FOR DELAYS, INTERRUPTIONS, SERVICE FAILURES OR OTHER PROBLEMS INHERENT IN USE OF THE INTERNET AND ELECTRONIC COMMUNICATIONS OR OTHER SYSTEMS OUTSIDE THE REASONABLE CONTROL OF AVEPOINT. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, AVEPOINT DOES NOT WARRANT THAT THE SOLUTIONS WILL MEET CUSTOMER’S REQUIREMENTS, WILL OPERATE IN ANY COMBINATION THAT MAY BE SELECTED FOR USE BY CUSTOMER OR IN COMBINATION WITH OTHER THIRD-PARTY SOFTWARE BEYOND THE THIRD- PARTY SOFTWARE EXPRESSLY APPROVED AS COMPLIANT IN THE DOCUMENTATION. EXCEPT AS TO COMPATIBILITY OF THE LICENSED SOFTWARE AS DESCRIBED IN AVEPOINT’S DOCUMENTATION, AVEPOINT MAKES NO WARRANTIES TO CUSTOMER WITH RESPECT TO CUSTOMER'S COMPUTER EQUIPMENT OR SYSTEM SOFTWARE OR ITS CAPACITY. FURTHERMORE, AVEPOINT DOES NOT WARRANT THAT ANY SOFTWARE ERRORS, DEFECTS, OR INEFFICIENCIES WILL BE CORRECTED, NOR DOES AVEPOINT ASSUME ANY LIABILITY FOR FAILURE TO CORRECT ANY SUCH ERROR, DEFECT OR INEFFICIENCY. AVEPOINT MAKES NO WARRANTY, AND CUSTOMER ASSUMES THE ENTIRE RISK, AS TO THE INTEGRITY OF ANY DATA AND THE RESULTS, CAPABILITIES, SUITABILITY, USE, NON-USE OR PERFORMANCE OF THE SOLUTIONS. IN NO EVENT SHALL AVEPOINT BE LIABLE TO CUSTOMER FOR ANY DAMAGES RESULTING FROM OR RELATED TO THE USE OF THE SOLUTIONS. CUSTOMER MAY HAVE OTHER STATUTORY RIGHTS, BUT THE DURATION OF STATUTORILY REQUIRED WARRANTIES, IF ANY, SHALL BE LIMITED TO THE SHORTEST PERIOD PERMITTED BY LAW.
Warranty; Limitation of Liability 6.1 Nothing in this Agreement shall be deemed a warranty and any and all warranties in respect of the Program are exclusively set forth in the warranty policy available at xxx.xxxxxxxxxxx.xxx or upon Licensee's request. 6.2 In no event shall Licensor (including its officers, directors, employees and agents and its suppliers and licensors) be liable to Licensee (including any other entity or person related to or affiliated with Licensee) for any incidental, consequential, indirect, special or punitive damages whatsoever, or for any lost profits or revenue, lost business opportunities, lost or inaccessible data or information, or other pecuniary loss, arising out of or relating to this Agreement or the subject matter hereof, whether liability is asserted in contract or tort (including negligence or strict product liability) or otherwise, and irrespective of whether Licensor (including its officers, directors, employees and agents and its suppliers and licensors) has been advised of the possibility of any such damage or loss. 6.3 In no event shall Licensor's (including its officers, directors, employees and agents and its suppliers and licensors) aggregate liability under or arising out of or relating to this Agreement or the subject matter hereof exceed the Fees paid by Licensee to Licensor hereunder for the license of the applicable Program. LICENSEE ACKNOWLEDGES THAT THE PRICING OF THE PROGRAM AND THE OTHER TERMS AND CONDITIONS OF THIS AGREEMENT REFLECT THE ALLOCATION OF RISK SET FORTH IN THIS AGREEMENT AND THAT LICENSOR WOULD NOT ENTER INTO THIS AGREEMENT WITHOUT THESE LIMITATIONS OF ITS LIABILITY. 6.4 The limitations of liability in Sections 6.1 and 6.2 above do not apply (a) with respect to product liability arising under laws implementing Council Directive 85/374/EEC of 25 July 1985 on the approximation of the laws, regulations and administrative provisions of the Member States concerning liability for defective products, to the extent liability cannot be contractually limited or disclaimed under such laws, (b) with respect to bodily injury, and (c) to the extent such damage or loss is the result of Licensor's intentional or grossly negligent conduct. Some States do not allow the exclusion or limitation of incidental or consequential damages, so the above limitations or exclusions may not apply to Licensee.
Warranty Obligations (a) Project Co represents, warrants and covenants that: (i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario; (ii) the Works shall be free of defects, including design defects, errors and omissions; and (iii) materials and equipment shall be of good quality and in compliance with this Project Agreement. (b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole. (c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario). (d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment. (e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense. (f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Warranty Limitations This Contractual Warranty does not warrant uninterrupted or error-free operation of the Product or cover normal wear and tear of the Product or costs related to the removal, installation, or troubleshooting of the customer's electrical systems. The warranty claims that relate to defects caused by any of the following factors are not covered by the Contractual Warranty: • Improper Use or Non-compliance with installation, commissioning, operation or maintenance instructions (i.e. not according to the operation & installation manual) • Unauthorized modifications, changes or attempted repairs, • Vandalism, destruction through external influence and/or persons/animals • Use in an unsuitable environment, including any environment or location that causes excessive wear and tear or dirt or dust or debris buildup within the system or that is difficult or unsafe for Xantrex LLC representatives to access • Insufficient ventilation • Installation in a corrosive environment • Failure to observe applicable safety standards & regulations • Damages during transportation or storage • Force majeure, examples include, but not limited to: fire, flood, earthquakes, storm damage, overvoltage & lightning strikes • Exposure to fire, water, snow, moisture, or liquid ingress (except for any such exposure to environmental conditions that your Product was specifically designed to withstand as indicated in the applicable specifications for your Product) • Used as a component part of a product expressly warranted by another manufacturer • If the original identification (trade-mark, serial number) markings have been defaced, altered, or removed • Consumable components of any type are not covered, including but not limited to fans, fuses and filters etc. • Cosmetic shortcoming which do not impair the use of the product for the intended purpose i.e. supply of energy Warranty claims also exclude: • Damages arising due to the fact that the use of the product for the intended purpose is no longer possible or only possible with restrictions as a result of amendments to the statutory provisions applicable to the operation of the product made after the delivery of the product • Compensation for damages related to loss of power production or business operation or any expenses incurred by customer towards repair & replacement of the product (including but not limited to labor, transportation, temporary power) • Cost arising from changes to existing PV systems or building installations or vehicle or marine vessel installation and like • Additional costs and expenses (i.e. shipping costs, travel, accommodation, meals, etc.) arising due to remote locations of the indicated geographies, including but not limited to islands and overseas territories
Warranty Disclaimers WE ARE LEASING THE EQUIPMENT TO YOU “AS-IS.” YOU HAVE SELECTED SUPPLIER AND THE EQUIPMENT BASED UPON YOUR OWN JUDGMENT. IN THE EVENT WE ASSIGN THIS AGREEMENT, OUR ASSIGNEE DOES NOT TAKE RESPONSIBILITIES FOR THE INSTALLATION OR PERFORMANCE OF THE EQUIPMENT. SUPPLIER IS NOT AN AGENT OF OURS AND WE ARE NOT AN AGENT OF SUPPLIER, AND NOTHING SUPPLIER STATES OR DOES CAN AFFECT YOUR OBLIGATIONS HEREUNDER. YOU WILL MAKE ALL PAYMENTS UNDER THIS AGREEMENT REGARDLESS OF ANY CLAIM OR COMPLAINT AGAINST ANY SUPPLIER, LICENSOR OR MANUFACTURER, AND ANY FAILURE OF A SERVICE PROVIDER TO PROVIDE SERVICES WILL NOT EXCUSE YOUR OBLIGATIONS TO US UNDER THIS AGREEMENT. WE MAKE NO WARRANTIES, EXPRESS OR IMPLIED, OF, AND TAKE ABSOLUTELY NO RESPONSIBILITY FOR, MERCHANTABILITY, FITNESS FOR ANY PARTICULAR PURPOSE, CONDITION, QUALITY, ADEQUACY, TITLE, DATA ACCURACY, SYSTEM INTEGRATION, FUNCTION, DEFECTS, INFRINGEMENT OR ANY OTHER ISSUE IN REGARD TO THE EQUIPMENT, ANY ASSOCIATED SOFTWARE AND ANY FINANCED ITEMS. SO LONG AS YOU ARE NOT IN DEFAULT UNDER THIS AGREEMENT, WE ASSIGN TO YOU ANY WARRANTIES IN THE EQUIPMENT GIVEN TO US.
Warranty Work Failure by the Contractor to take corrective action within twenty four (24) hours after personal or telephonic notice by the County's OC Public Works on items affecting essential use of the facility, safety or the preservation of property, and within ten (10) calendar days following written notice on other deficiencies, will result in the County taking whatever corrective action it deems necessary. All costs resulting from such action by the County will be claimed against Contractor or, if necessary, the Contractor's Performance Bond.
Warranty Limitation We do not warrant that the operation of Software will be uninterrupted or error free, or that Software will operate in hardware and Software combinations other than as expressly required by us in the Product specifications or that Software will meet your requirements.
Lost Items The Credit Union, in receiving items from you for withdrawal or deposit, acts only as your agent and reserves the right to reverse the credit for any deposited items or to charge your account for the items should they become lost in the collection process.
