Feasibility Study A feasibility study will identify the potential costs, service quality and other benefits which would result from contracting out the work in question. The cost analysis for the feasibility study shall not include the Employer’s indirect overhead costs for existing salaries or wages and benefits for administrative staff or for rent, equipment, utilities, and materials, except to the extent that such costs are attributable solely to performing the services to be contracted out. Upon completion of the feasibility study, the Employer agrees to furnish the Union with a copy if the feasibility study, the bid from the Apparent Successful Bidder and all pertinent information upon which the Employer based its decision to contract out the work including, but not limited to, the total cost savings the Employer anticipates. The Employer shall not go forward with contracting out the work in question if more than sixty percent (60%) of any projected savings resulting from the contracting out are attributable to lower employee wage and benefit costs.
Commencement and Completion 3.1 The Owner agrees to commence the Restoration Works, Landscaping Works, and Servicing Works forthwith upon adoption of City of Kelowna Heritage Revitalization Agreement Authorization Bylaw No. and to complete the Works no later than August 1, 2006.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed. 2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County. 2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract. 2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief. 2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System. 4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA. 4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. 4.1.5 The Power Producer shall commission the Project within SCOD. 4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer. 4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
Decommissioning (a) The Contractor shall submit to the Designated Authority, for its approval, pursuant to sub-paragraph 4.11(d)(v), a Decommissioning Plan for the Development Area and a schedule of provisions for the Decommissioning Costs Reserve. (b) The Decommissioning Plan shall be revised and resubmitted to the Designated Authority for its approval at such times as are reasonable having regard to the likelihood that the Decommissioning Plan (including cost estimates thereunder) may need to be revised. (c) The Contractor shall carry out the Decommissioning Plan substantially in accordance with its terms. (d) Estimates of the monies required for the funding of the Decommissioning Plan shall be charged as Recoverable Costs beginning in the Calendar Year following the Calendar Year in which Commercial Production first occurs. The amount charged in each Calendar Year shall be calculated as follows: (i) The total Decommissioning costs at the expected date of Decommissioning shall first be calculated. (ii) There shall be deducted from such total Decommissioning costs the additions made to the Decommissioning Costs Reserve made, and taken as Recoverable Costs, in all previous Calendar Years together with interest on such Recoverable Costs calculated to the approved date of Decommissioning at the actual or forecast rate of Uplift (whichever is applicable). (iii) The residual Decommissioning costs, resulting from the calculations under sub-paragraph 4.14(d)(i) and (ii), shall then be discounted to the Calendar Year in question at the forecast rate of Uplift for each Calendar Year remaining until the Calendar Year of Decommissioning. (iv) The discounted total of residual Decommissioning costs shall then be divided by the total number of Calendar Years remaining prior to the Calendar Year of Decommissioning itself, including the Calendar Year in question. (v) The resultant amount shall be the addition to the Decommissioning Costs Reserve for the Calendar Year in question. (vi) It is the intention of this provision that the total accumulated provision allowed, including interest calculated to the Calendar Year of Decommissioning at the rate of Uplift, will equal the total Decommissioning costs. (vii) If the amount in sub-paragraph 4.14(d)(v) is a negative amount, then such amount shall be treated as a reduction of Recoverable Costs for the Calendar Year in question.
Commissioning Commissioning tests of the Interconnection Customer’s installed equipment shall be performed pursuant to applicable codes and standards. The ISO and Connecting Transmission Owner must be given at least five Business Days written notice, or as otherwise mutually agreed to by the Parties, of the tests and may be present to witness the commissioning tests.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: § 3.2 The Contract Time shall be measured from the date of commencement of the Work.