Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
No Unauthorized Use Provider shall not use Student Data or information in a Pupil Record for any purpose other than as explicitly specified in this DPA.
No Unlawful or Prohibited Use Intellectual Property
Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.
No Unauthorized Use or Disclosure Executive agrees that he will not, at any time during or after Executive’s employment by Company, make any unauthorized disclosure of, and will prevent the removal from Company premises of, Confidential Information or Work Product of Company (or its affiliates), or make any use thereof, except in the carrying out of Executive’s responsibilities during the course of Executive’s employment with Company. Executive shall use commercially reasonable efforts to cause all persons or entities to whom any Confidential Information shall be disclosed by him hereunder to observe the terms and conditions set forth herein as though each such person or entity was bound hereby. Executive shall have no obligation hereunder to keep confidential any Confidential Information if and to the extent disclosure thereof is specifically required by law; provided, however, that in the event disclosure is required by applicable law, Executive shall provide Company with prompt notice of such requirement prior to making any such disclosure, so that Company may seek an appropriate protective order. At the request of Company at any time, Executive agrees to deliver to Company all Confidential Information that he may possess or control. Executive agrees that all Confidential Information of Company (whether now or hereafter existing) conceived, discovered or made by him during the period of Executive’s employment by Company exclusively belongs to Company (and not to Executive), and Executive will promptly disclose such Confidential Information to Company and perform all actions reasonably requested by Company to establish and confirm such exclusive ownership. Affiliates of Company shall be third party beneficiaries of Executive’s obligations under this Article 6. As a result of Executive’s employment by Company, Executive may also from time to time have access to, or knowledge of, Confidential Information or Work Product of third parties, such as customers, suppliers, partners, joint venturers, and the like, of Company and its affiliates. Executive also agrees to preserve and protect the confidentiality of such third party Confidential Information and Work Product to the same extent, and on the same basis, as Company’s Confidential Information and Work Product.
Waiver of Jury Trial, Punitive Damages, etc BORROWER, ADMINISTRATIVE AGENT, AND EACH BANK HEREBY (a) KNOWINGLY, VOLUNTARILY, INTENTIONALLY, AND IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY LITIGATION BASED HEREON, OR DIRECTLY OR INDIRECTLY AT ANY TIME ARISING OUT OF, UNDER OR IN CONNECTION WITH THE LOAN PAPERS OR ANY TRANSACTION CONTEMPLATED THEREBY OR ASSOCIATED THEREWITH, BEFORE OR AFTER MATURITY; (b) IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO CLAIM OR RECOVER IN ANY SUCH LITIGATION ANY “SPECIAL DAMAGES,” AS DEFINED BELOW; (c) CERTIFY THAT NO PARTY HERETO NOR ANY REPRESENTATIVE OR AGENT OR COUNSEL FOR ANY PARTY HERETO HAS REPRESENTED, EXPRESSLY OR OTHERWISE, OR IMPLIED THAT SUCH PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK TO ENFORCE THE FOREGOING WAIVERS, AND (d) ACKNOWLEDGE THAT IT HAS BEEN INDUCED TO ENTER INTO THIS AGREEMENT, THE OTHER LOAN PAPERS AND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS CONTAINED IN THIS SECTION. AS USED IN THIS SECTION, “SPECIAL DAMAGES” INCLUDES ALL SPECIAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES (REGARDLESS OF HOW NAMED), BUT DOES NOT INCLUDE ANY PAYMENT OR FUNDS WHICH ANY PARTY HERETO HAS EXPRESSLY PROMISED TO PAY OR DELIVER TO ANY OTHER PARTY HERETO.
No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.
Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.
Direct Damages A PARTY’S DAMAGES RESULTING FROM A BREACH OR VIOLATION OF ANY REPRESENTATION, WARRANTY, COVENANT, AGREEMENT OR CONDITION CONTAINED IN THIS AGREEMENT OR ANY ACT OR OMISSION ARISING FROM OR RELATED TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DIRECT DAMAGES AND SHALL NOT INCLUDE ANY OTHER LOSS OR DAMAGE, INCLUDING INDIRECT, SPECIAL, CONSEQUENTIAL, INCIDENTAL, EXEMPLARY OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, PRODUCTION, OR REVENUES, AND EACH PARTY RELEASES THE OTHER PARTY FROM ALL SUCH CLAIMS FOR LOSS OR DAMAGE OTHER THAN ACTUAL DIRECT DAMAGES; PROVIDED THAT THIS LIMITATION TO DIRECT DAMAGES SHALL NOT LIMIT THE PARTIES’ INDEMNIFICATION OBLIGATIONS UNDER Section 3.5(c), Section 7.3, AND Article 15.
No Punitive Damages If any dispute arises regarding the application, interpretation or enforcement of any provision of this Agreement, including fraud in the inducement, the parties hereby waive their right to seek punitive damages in connection with said dispute.
