Base Building Architect definition

Base Building Architect means the architect for the Base Building Work, who shall be designated by Landlord.
Sample 1Sample 2
Base Building Architect means Xxxxxxx Associates a Partnership of Corporations of 00 Xxxx Xxxxxx Xxxx Xxxxxxxxxxx Xxxxxxx X00 0X0 Xxxxxx or such other firm as is appointed to perform the function of issuing the Base Building Works Practical Completion Certificate
Sample 1
Base Building Architect means TVS-Design, together with any replacements thereof selected by Construction Agent and approved by Landlord, such approval not to be unreasonably withheld, conditioned or delayed.
Sample 1

Examples of Base Building Architect in a sentence

  • The Base Building Architect shall certify in writing the date of Substantial Completion, and Landlord shall cause a copy of such certification to be delivered to Tenant.

  • Representatives of Landlord and Tenant shall accompany the Base Building Architect and the Base Building Contractor on a walk-through and inspection of the Premises to determine if final completion has occurred.

  • In order to expedite completion of the School Base Building Work, if in the reasonable judgment of the School Base Building Architect the same are complete and integrated enough for SCA to review and comment on, Developer may request SCA to review mechanical, electrical and plumbing plans and specifications, pre-purchase specifications and long lead items.

  • Schedule 2 hereto sets out the time schedule for submittal of the Base Building Design Development Documents to Tenant, for Tenant’s comments thereon to Landlord and the Base Building Architect, and for the resubmittal of revised Base Building Design Development Documents by the Base Building Architect to Tenant.

  • Landlord's invoices shall be accompanied by copies of the pertinent requisition(s) received by Landlord from Landlord's general contractor, which requisitions shall have been approved in writing by the Base Building Architect as ready for payment.

  • Tenant's Designated Representative and Tenant’s Consultant (if any) will have the right to attend scheduled meetings material to the interest of Tenant as may be held with respect to the Property between Landlord, General Contractor, the Base Building Architect, the Leasehold Improvement Architect, and any other outside person or firm (other than Landlord's attorneys or accountants) furnishing materials, services, or labor to or with respect to the Property.

  • In order to expedite completion of the Base Building Work, if in the reasonable judgment of the Base Building Architect the same are complete and integrated enough for Tenant to review and comment, Landlord may request Tenant to approve pre-purchase specifications and long lead items prior to final approval of the Base Building CD's.

  • Prior to Tenant's commencement of any Tenant Improvement Work, representatives of Landlord and Tenant shall accompany the Base Building Architect and the Base Building Contractor on a walk through and inspection to identify items of the construction of the Base Building Work (other than improvements outside of the Buildings) that are completed and that are not completed.

  • Within a reasonable period of time (not to exceed 60 days) after Substantial Completion of the Base Building Work, Landlord shall cause the Base Building Architect to certify the Actual Tenant Delay.

  • The Certificate of Payment is executed by the sub recipient, the contractor, the consultant, and the PID representative prior to being processed for payment.


More Definitions of Base Building Architect

Base Building Architect means RLC Architects P.A., or such other firm (and their consultants) which may hereafter be designated by Landlord and approved in writing by Tenant, which approval shall not be unreasonably withheld, delayed, or conditioned, that are providing design or consulting services required incident to the design and construction of the Base Building by the Landlord. Landlord will provide a copy of the contract or other written agreement between Landlord and the Base Building Architect promptly upon written request of Tenant.
Sample 1
Base Building Architect will mean Rxxxxxx, XxxXxxxx & Bxxxxxx, Inc., or such other firm which may hereafter be designated by Landlord and approved in writing by Tenant, in Tenant's reasonable discretion.
Sample 1

Related to Base Building Architect

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Building Common Areas means with respect to the Tower, the areas, facilities and amenities specified in Schedule [E] which are to be used and enjoyed in common with all the other Apartment Acquirers of the Units in the Building; and

  • Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.

  • Building Square Footage or "BSF" means the square footage of assessable internal living space of a Unit, exclusive of any carports, walkways, garages, overhangs, patios, enclosed patios, detached accessory structure, other structures not used as living space, or any other square footage excluded under Government Code Section 65995 as determined by reference to the Building Permit for such Unit.

  • Building Area means the greatest horizontal area of a building within the outside surface of the exterior walls.

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Building system means plans, specifications and docu- mentation for a system of manufactured building or for a type or a system of building components, which may include structural, electrical, mechanical, plumbing and variations which are sub- mitted as part of the building system.

  • Building site means a plot of land held for building purposes, whether any building is actually erected thereupon or not, and includes the open ground or courtyard enclosed by, or adjacent to, any building erected thereupon;

  • Building Contractor means the building contractor or developer appointed or to be appointed by the Grant Recipient in respect of a Firm Scheme; Business Day means any day other than a Saturday, Sunday or a statutory Bank Holiday in England;

  • mixed-use building means a building or structure containing a residential and non- residential use other than a home occupation;

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Architect/Engineer means the person designated by the Commissioner to provide the Contract drawings and Detailed Specifications for the Work you are to perform.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Building construction means any physical activity on the site involved in the erection of a structure, cladding, external finish, formwork, fixture, fitting of service installation and the unloading of plant, machinery, materials or the like.

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.