Base Building Works definition

Base Building Works means the construction of the Base Building in respect of which practical completion occurred on 7 March 2003;
Sample 1Sample 2
Base Building Works means the construction of the Building in accordance with the Plans and Specifications;
Sample 1
Base Building Works means the construction of the Base Building as the same may be modified from time to time in accordance with this Agreement
Sample 1

Examples of Base Building Works in a sentence

  • Monetary Contribution Business Innovation Space Fitout $8,140,000 (as estimated) being an amount calculated on a rate of $2,200 per square metre x net lettable area of the Premises and indexed in accordance with paragraph 2.2 below To be paid no later than 3 months prior to Completion of the Business Innovation Space Base Building Works for the Premises as reasonably anticipated by the Developer See clause 2 of Schedule 3.

  • The certificate of practical completion of the Base Building Works was issued on 7 March 2003, a copy of which has been provided to the Tenant prior to the date of this Agreement.

  • Defects in the Base Building Works ...............................

  • The Developer confirms that it shall not specify or knowingly authorise and shall procure that CWCL shall not specify or knowingly authorise any of the Prohibited Materials for use in the Base Building Works and that it has used and will continue to use the skill and care required by clause 6.

  • The Landlord agrees to obtain a one (1) year warranty from its general contractor and the Landlord agrees to diligently enforce such warranty on materials, labour and workmanship from its general contractor with respect to the Base Building Works and Tenant Improvements for the benefit of the Tenant.

  • Defects Costs in respect of Base Building Works ..................

  • Save as provided in Clause 4.2, no consent from the Tenant shall be required for any detailing of the Base Building Works or other adjustment which does not comprise a material variation thereof provided that such further detailing or adjustment shall in all material respects be consistent with and in conformity with the Base Building Specification and/or the TRM Specification as relevant.

  • The Certifying Officer shall be instructed by the Developer to have regard to (but shall not be bound by) any representations made by the Developer and/or the Tenant and/or the Fit Out Architect during such inspection or made forthwith in writing thereafter as to the state and condition of the Base Building Works.

  • The Developer shall be responsible for carrying out any works which prove to be necessary to enable any plant and machinery or installations forming part of the Base Building Works to be initially commissioned and the Tenant shall be responsible for procuring the carrying out of any works which require to be done in order to enable any plant or machinery or installations forming part of the Fit Out Works to be commissioned.

  • This will allow the Landlord and the Tenant's Consultant to fairly and accurately separate the cost of the Leasehold Improvements from that of the Base Building Works.


More Definitions of Base Building Works

Base Building Works has the same meaning as in the Tenant’s Defect Deed;
Sample 1
Base Building Works means the construction of the Office Component (excluding the Initial Leasehold Improvements) in accordance with the Plans and Specifications and shall include the work described in Schedule “G” attached hereto as Landlord’ s Work;
Sample 1
Base Building Works means the aggregate of the Demolition Works and the construction of the Base Building in accordance with the Base Building Specification and the Base Building Plans (but excluding (for the avoidance of doubt otherwise than as provided for in Clause 39.4) the Bridge Works (as defined in the Bridge Agreement) and the Tunnel Works (as defined in the Tunnel Agreement) and omitting the Category A Works but including any Tenant's Requested Modifications which are to be carried out by the Developer pursuant to Clause 9) as the same may be varied from time to time under Clause 8
Sample 1

Related to Base Building Works

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Tenant Improvements Defined in Exhibit B, if any.

  • Building Systems means any electrical, mechanical, structural, plumbing, heating, ventilating, air conditioning, sprinkler, life safety or security systems serving the Building.

  • Building Common Areas means with respect to the Tower, the areas, facilities and amenities specified in Schedule [E] which are to be used and enjoyed in common with all the other Apartment Acquirers of the Units in the Building; and

  • Building system means plans, specifications and docu- mentation for a system of manufactured building or for a type or a system of building components, which may include structural, electrical, mechanical, plumbing and variations which are sub- mitted as part of the building system.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.

  • mixed-use building means a building or structure containing a residential and non- residential use other than a home occupation;

  • Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Common Areas is defined as all areas and facilities outside the Premises and within the exterior boundary line of the Project and interior utility raceways and installations within the Unit that are provided and designated by the Lessor from time to time for the general non-exclusive use of Lessor, Lessee and other tenants of the Project and their respective employees, suppliers, shippers, customers, contractors and invitees, including parking areas, loading and unloading areas, trash areas, roadways, walkways, driveways and landscaped areas.

  • Common Area means all areas and facilities within the Project that are not designated by Landlord for the exclusive use of Tenant or any other lessee or other occupant of the Project, including the parking areas, access and perimeter roads, pedestrian sidewalks, landscaped areas, trash enclosures, recreation areas and the like.

  • Leasehold Improvements means all buildings, structures, improvements and fixtures located on any Leased Real Property which are owned by any Group Company, regardless of whether title to such buildings, structures, improvements or fixtures are subject to reversion to the landlord or other third party upon the expiration or termination of the Lease for such Leased Real Property.

  • Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • piece-work means any system by which earnings are calculated upon the quantity or output of work performed;

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Common Areas and Facilities means collectively the Development Common Areas and Facilities and the Residential Common Areas and Facilities and all those parts and such of the facilities of the Development designated as common areas and facilities in any Sub-Deed;

  • Building Square Footage or "BSF" means the square footage of assessable internal living space of a Unit, exclusive of any carports, walkways, garages, overhangs, patios, enclosed patios, detached accessory structure, other structures not used as living space, or any other square footage excluded under Government Code Section 65995 as determined by reference to the Building Permit for such Unit.

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.