Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Substantial Completion Date means the date on which Substantial Completion occurs.
TLR means the NERC Transmission Loading Relief Procedures used in the Eastern Interconnection as specified in NERC Operating Policies.
Substantially Completed or “Substantial Completion” means that (i) Landlord has completed the Finish Work in accordance with the Working Plans, except for (x) minor details of construction that will not unreasonably interfere with Tenant’s use of the Premises (collectively, “Punch List Items”), and (y) any part of the Finish Work that is not completed due to any act or omission of Tenant or Tenant’s Visitors; and (ii) Landlord has obtained a valid temporary or permanent certificate of occupancy for the Premises (provided that any such temporary certificate of occupancy permits occupancy of the Premises and provided that Landlord delivers a copy of the permanent certificate of occupancy to Tenant promptly upon receipt of same) or, alternatively, Landlord has completed all Finish Work necessary to entitle Landlord to the issuance of a temporary or permanent certificate of occupancy but for the completion of any Finish Work that is not completed due to any act or omission of Tenant or Tenant’s Visitors (in which case, Landlord shall diligently pursue such temporary or permanent certificate of occupancy following the completion of any such Finish Work that is not completed due to any such act or omission of Tenant or Tenant’s Visitors). If the completion of the Finish Work is delayed due to any act or omission by Tenant or Tenant’s Visitors, including, but not limited to, delays due to changes in or additions to the Finish Work requested by Tenant, delays in submission of information or estimates, delays in giving authorizations or approvals, or delays due to the postponement of any work at the request of Tenant, then the date set forth in paragraph (7) of the Basic Lease Provisions on which Tenant actually begins to pay Basic Rent will be accelerated by the number of days of delay caused by Tenant and Tenant’s Visitors (any such delay being referred to herein as a “Tenant Delay”).
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
Debilitating medical condition means one or more of the following:
Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.
Substantially Complete or “Substantial Completion” shall mean that (a) the Base Building Improvements that are required to permit Tenant to enter the Premises for purposes of performing the Tenant Improvement have been completed in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to commence the Tenant Improvement Work and (b) Tenant is legally permitted to enter the Premises for purposes of performing the Tenant Improvement Work. Landlord and Tenant shall then arrange a mutually convenient time, no later than ten (10) Business Days after the anticipated Substantial Completion Date specified in Landlord’s notice, for Tenant and/or Tenant’s Architect (as defined below) and Landlord and/or Landlord’s Architect to conduct a walk-through inspection of the Base Building Improvements. During the inspection, Landlord’s Architect shall compile a punchlist of items yet to be completed. If Tenant or Tenant’s Architect shall fail to inspect the Base Building Improvements within ten (10) Business Days after the Substantial Completion Date specified in Landlord’s notice, the Base Building Improvements shall be deemed completed and satisfactory in all respects, and the Substantial Completion Date shall be the date set forth in Landlord’s notice. Landlord shall use commercially reasonable efforts to cause the remaining Base Building Improvements to have been completed on or before the Term Commencement Date in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to occupy the Premises to commence the Tenant Improvement Work
Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.
Commissioning test means tests applied to a distributed generation facility by the applicant after construction is completed to verify that the facility does not create adverse system impacts and performs to the submitted specifications. At a minimum, the scope of the commissioning tests performed shall include the commissioning test specified in Institute of Electrical and Electronics Engineers, Inc. (IEEE) Standard 1547 Section 5.4 "Commissioning tests".
Congenital Condition(s) means (a) any medical, physical or mental abnormalities existed at the time of or before birth, whether or not being manifested, diagnosed or known at birth; or (b) any neo-natal abnormalities developed within six (6) months of birth.
Capitol hill complex means the grounds and buildings within the area bounded by 300 North Street, Columbus Street, 500 North Street, and East Capitol Boulevard in Salt Lake City.
Tare Weight means the weight of an empty shipping container, excluding all materials used for wrapping, cushioning, banding, waterproofing, packaging, blocking and bracing articles within the exterior container.
Project Completion Date means the date on which the Completion Certificate is issued;
Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:
Congenital Anomaly means a condition which is present since birth, and which is abnormal with reference to form, structure or position.
Aquatic invasive species means any invasive, prohibited,
Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.
Commissioning Date means that date when construction of the contemplated Project is complete, and the Maintenance Term commences;
Certified scale weigh ticket means a weigh ticket that has been issued by a
Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.
Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.
Invasive species means an alien species whose introduction does or is likely to cause economic or environmental harm or harm to human health.
Peak tube potential means the maximum value of the potential difference across the x-ray tube during an exposure.
Target Completion Date has the meaning given such term in Section 3.3(b).