Contract Substantial Completion Date definition

Contract Substantial Completion Date means the date set forth on Exhibit B attached hereto for Substantial Completion of the Work, as such date may be adjusted pursuant to the terms of the Contract Documents.
Sample 1Sample 2Sample 3
Contract Substantial Completion Date shall have the meaning set forth in the Contractor’s Statement.
Sample 1Sample 2

Examples of Contract Substantial Completion Date in a sentence

  • Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date".

  • The parties agree that the Owner will be substantially damaged in amounts that will be difficult or impossible to determine if Substantial Completion or Final Acceptance is not achieved by the Contractor on or before the Contract Substantial Completion Date and/or Contract Final Acceptance Date set forth herein.

  • Contractor Groathouse Construction, Inc.Laramie, WYGuaranteed Maximum Price $19,800,000 Contract Substantial Completion Date January 15, 2015 (In Thousands)TotalAdminConstrDesignTechFF&EMiscCntngcyBudget26,91991219,8002,922974974637700Expended4,2895032,5741,19700150Obligated17,969017,226523000220Un-obligated4,66140901,202974974622480 Remarks Foundation construction and related earthwork is generally in place, including drilled piers and grade beams.

  • The parties therefore agree that if Substantial Completion does not occur by the Contract Substantial Completion Date for any reason not the fault of the Owner or otherwise constituting an excusable delay, the Owner shall be entitled to liquidated damages in the amount of $1000 per calendar day for each day the Substantial Completion of the project, or any phase thereof, is delayed beyond the Contract Substantial Completion Date in lieu of actual damages for such delays.

  • Contractor Haselden Wyoming Constructors Casper, WYGuaranteed Maximum Price $7,099,599 Contract Substantial Completion Date September 29, 2014 (In Thousands)TotalAdminConstrDesignTechFF&EMiscCntngcyBudget12,85041510,2921,06525042740361Expended3523203200000Obligated7,78707,1006870000Un-obligated4,7113833,1925825042740361 Remarks Bid packages for video boards, scoreboards and seating are being prepared for early bid advertising due to long lead times on production and procurement.

  • The date which is 60 calendar days past the Notice to Proceed shall be the Contract Substantial Completion Date.

  • Energy Innovation Center Construction Manager at Risk G E Johnson Construction CompanyJackson, WYGuaranteed Maximum Price $18,926,514 Contract Substantial Completion Date June 4, 2012 Extended June 7, 2013 (In Thousands)TotalAdminConstrDesignTechFF&EMiscCntngcyBudget25,40068619,3481,8551,0701,007507927Expended28,66360622,7051,8551,070993507927Obligated00000000Other Funding3,35703,35700000Un-obligated94800001400 Remarks Warranty review was done in November.

  • Powell Seed Analysis LaboratoryContractor: Jim’s Building ServiceBid Price: $254,618.00Original Completion Date: 11 April 2003 Contract Substantial Completion Date: N/A TotalAdministrationConstructionDesignContingencyBudget325,00012,731254,61820,98036,671Expended39,9286,04518,14815,735-Obligated241,715-236,4705,245-Un-obligated43,3576,686--36,671Remarks: Laboratory and Germination Room HVAC design services are being provided by the Facilities Planning Office.

  • Construction Manager at Risk FCI Constructors, Inc.Longmont, COGuaranteed Maximum Price $38,075,000 Contract Substantial Completion Date August 31, 2009 (In Thousands)TotalAdminConstrDesignFF&EMiscCntngcyBudget50,0301,34638,0752,7004,4301,7881,691Expended33,83558028,0772,4311,9707770Obligated11,419011,37247000Other Funding2,29402,2940000Un-obligated7,0707669202222,4601,0111,691 Remarks Finish work continues in the addition.

  • Contractor Groathouse Construction, Inc.Laramie, WYGuaranteed Maximum Price $19,800,000 Contract Substantial Completion Date January 15, 2015Extended March 31, 2015 (In Thousands)TotalAdmin Remarks Occupancy of the Phase I eastern reconstruction/addition portion of the Half Acre Recreation and Wellness Center is expected take place the week of March8.

Related to Contract Substantial Completion Date

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Contract Start Date means the date specified in your Contract for Signature as the date this Contract starts;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.