Guaranteed Substantial Completion Dates definition

Guaranteed Substantial Completion Dates has the meaning set forth in Section 5.3B.
Sample 1Sample 2Sample 3
Guaranteed Substantial Completion Dates as defined in the SPL Common Terms Agreement.
Sample 1Sample 2
Guaranteed Substantial Completion Dates means the Guaranteed Stage I Substantial Completion Date and the Guaranteed Stage II Substantial Completion Date, collectively.
Sample 1

Examples of Guaranteed Substantial Completion Dates in a sentence

  • The Guaranteed Substantial Completion Dates shall only be adjusted by Change Order as provided under this Agreement.

  • Contractor shall be entitled to an extension to the applicable Target Substantial Completion Dates and/or Guaranteed Substantial Completion Dates for delay or prevention that meets the requirements of this Section 6.8A, if and to the extent such delay or prevention causes a delay in the critical path of the Work.

  • Owner’s review and comments regarding the Recovery Schedule shall not relieve Contractor of any obligations for performance of the Work, change the Target Substantial Completion Dates or Guaranteed Substantial Completion Dates or be construed to establish the reasonableness of the Recovery Schedule.

  • Even if the Work is otherwise in compliance with the CPM Schedule, Owner may, at any time, direct Contractor in writing to advance one or all of the Target Substantial Completion Dates and Guaranteed Substantial Completion Dates; provided, however, such directive shall be reasonable and Contractor shall have agreed in writing that such acceleration is commercially and technically feasible.

  • All Change Order Requests shall include documentation sufficient to enable Owner to determine: (a) the factors necessitating the possibility of a Change; (b) the impact which the Change is likely to have on the Contract Price; (c) the impact which the Change is likely to have on the timely achievement of the activities set forth in the Project Schedule (including the Guaranteed Substantial Completion Dates); and (d) such other information which Owner may request in connection with such Change.

  • In preparing such Change Order, the Parties will work toward the goal of maintaining the Guaranteed Substantial Completion Dates as stated above.

  • Unless otherwise mutually agreed upon by the Parties, Contractor shall revise and update the Project Schedule quarterly prior to the commencement of on-Site construction work and monthly thereafter and shall provide a copy to Owner, which may be provided electronically; provided, however, that the Guaranteed Substantial Completion Dates for the Units shall not be revised other than pursuant to Article 9.

  • In no event shall Owner have the right to issue a unilateral acceleration directive requiring Contractor to achieve Substantial Completion of Subproject 1 or Substantial Completion of Subproject 2 prior to the original Guaranteed Substantial Completion Dates specified in this Agreement as of the Contract Date, as applicable.

  • Similarly, to the extent that a Change enhances Contractor's or its Subcontractors' ability to perform the Work, reduces the cost of the Work or its other obligations under this Agreement, or shortens the Project Schedule, Owner shall be entitled to an equitable adjustment as appropriate to the Contract Price, the Project Schedule, the Milestone Payment Schedule, the Guaranteed Substantial Completion Dates, the Scope of Work and/or such other parts of this Agreement as may be affected by such Change.

  • Once the event that allowed Contractor to suspend Work under this Section 22.4(a) has occurred, Owner and Contractor shall negotiate a Change in the Contract Price, Project Schedule (including the Guaranteed Substantial Completion Date(s)), and such other applicable terms and conditions of this Agreement to reflect the effect of such event, including, without limitation, the suspension of the Work, and the demobilization and remobilization of Contractor's and the Subcontractors' forces, as applicable.


More Definitions of Guaranteed Substantial Completion Dates

Guaranteed Substantial Completion Dates has the meaning set forth in Section 5.3B as may be adjusted by Change Order in accordance with the terms of this Agreement.
Sample 1
Guaranteed Substantial Completion Dates as defined in the SPL Common Terms Agreement. “Guaranty” means the guaranty of each Subsidiary Guarantor set forth in Section 7 (Guaranty).
Sample 1

Related to Guaranteed Substantial Completion Dates

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Guaranteed Construction Start Date means the Expected Construction Start Date, as such date may be extended by the Development Cure Period.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Rent Commencement Date means [Insert date or description] or any later date calculated in accordance with paragraph 3.3 of Part 5 of the Schedule;

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Pre commencement condition means a condition imposed on the grant of permission which must be complied with: before any building/ other operation/ or use of the land comprised in the development is begun.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.