Initial Delivery Deadline definition

Initial Delivery Deadline has the meaning set forth in Section 2.05.
Sample 1Sample 2Sample 3
Initial Delivery Deadline means *** .
Sample 1Sample 2Sample 3
Initial Delivery Deadline means not later than 12:00 p.m. New York City time on July 31, 2009.
Sample 1

Examples of Initial Delivery Deadline in a sentence

  • To extend the Initial Delivery Deadline under this Section 2.06(c), Seller must, no later than 6:00 a.m. on the third Business Day immediately prior to the first day of the proposed Initial Delivery Deadline extension, provide SCE with Notice of its election to extend the Initial Delivery Deadline along with Seller’s estimate of the duration of the extension and its payment of Daily Delay Liquidated Damages for the full estimated Initial Delivery Deadline extension period.

  • The Daily Delay Liquidated Damages payments applicable to days included in any Initial Delivery Deadline extension are nonrefundable (subject to the next paragraph of this Section 2.06) and are in addition to, and not a part of, the Development Security.

  • This process shall apply to the original Initial Delivery Deadline extension period and any subsequent extensions.

  • Subject to Section 2.06(d), Seller may extend the Initial Delivery Deadline for up to one-hundred and eighty (180) days by paying to SCE liquidated damages in an amount equal to one percent (1%) of the Development Security per day for each day (or portion thereof) from and including the Initial Delivery Deadline to and excluding the actual date that the Project achieves the Initial Delivery Date (“Daily Delay Liquidated Damages”).

  • Notwithstanding anything in this Agreement to the contrary, the Initial Delivery Deadline may not be later than the first day of the month occurring forty-eight (48) months after CPUC Approval (the “Guaranteed Delivery Deadline”).

  • In no event may Seller extend the Initial Delivery Deadline beyond the Guaranteed Delivery Deadline as a result of the failure to obtain Permits, due to interconnection delay, Force Majeure, or by payment of Daily Delay Liquidated Damages, or any combination thereof.

  • Notwithstanding anything in this Agreement to the contrary, the Initial Delivery Deadline may not be later than [Date] (the “Guaranteed Delivery Deadline”).

  • Seller must achieve the Initial Delivery Date on or before the Initial Delivery Deadline.

  • For the avoidance of doubt, there shall be no extension of the Initial Delivery Deadline, for Force Majeure or otherwise.

  • As soon as reasonably practicable after the termination of this Agreement by either Party pursuant to Sections 2.07, 5.01(b) or 8.03(a), SCE shall return to Seller the full Development Security; provided, a termination under Article 8 only entitles Seller to a return of the Development Security if the termination is based on a Force Majeure that prevents the Initial Delivery Date from occurring on or before the Initial Delivery Deadline.

Related to Initial Delivery Deadline

  • Initial Delivery Date has the meaning set forth in Section 1.1(d).

  • Final Delivery Date means the date the Supplier is entitled to deliver the Products form the Purchaser even if the Products have not been called off as agreed in any Sales Agreement.

  • First Delivery Date means the first date by which the commodity for a Futures Contract can be delivered in order for the terms of the Futures Contract to be fulfilled.

  • Contractual Delivery Date means the stipulated date on which the contractor shall attain

  • Warrant Share Delivery Date shall have the meaning set forth in Section 2(d)(i).

  • Final delivery certificate means the document issued by the COE confirming that all the known defects have been rectified and that the works, goods or services appear in good order and have been accepted;

  • Share Delivery Date shall have the meaning set forth in Section 4(c)(ii).

  • Exercise Notice Deadline In respect of any exercise of Options hereunder on any Conversion Date, the “Scheduled Trading Day” prior to the scheduled first “VWAP Trading Day” of the “Observation Period” (each as defined in the Indenture, but, in the case of any such Observation Period, as modified by the provision set forth opposite the caption “Convertible Security Settlement Method”) relating to the Convertible Securities converted on the Conversion Date occurring on the relevant Exercise Date; provided that in the case of any exercise of Options hereunder in connection with the conversion of any Relevant Convertible Securities on any Conversion Date occurring during the period starting on and including June 4, 2020 and ending on and including the second “Scheduled Trading Day” immediately preceding the “Maturity Date” (each as defined in the Indenture) (the “Final Conversion Period”), the Exercise Notice Deadline shall be noon, New York City time, on the “Scheduled Trading Day” (as defined in the Indenture) immediately preceding the “Maturity Date” (as defined in the Indenture).

  • Issuance Notice Date means any Trading Day during the Agency Period that an Issuance Notice is delivered pursuant to Section 3(b)(i).

  • Delivery Date means the date or dates specified in the Purchase Order by which the Supplier is required to deliver the Work.

  • Delivery Day means a day other than a Saturday, a Sunday or any other day on which national banking associations are authorized to be closed. Any party may change its address for purposes of the receipt of notices and demands by giving notice of the change in the manner provided in this provision.

  • Mailing Date has the meaning set forth in Section 2.1(a).

  • Forced Conversion Notice Date shall have the meaning set forth in Section 6(d).

  • Locational Deliverability Area or “LDA” shall mean a geographic area within the PJM Region that has limited transmission capability to import capacity to satisfy such area’s reliability requirement, as determined by the Office of the Interconnection in connection with preparation of the Regional Transmission Expansion Plan, and as specified in Reliability Assurance Agreement, Schedule 10.1.

  • Notice Delivery Period means the period from and including the Trade Date, to and including a day that is three (3) Business Days following the date that is 14 calendar days after the Scheduled Termination Date. Section 1.23 (Notice Delivery Period) of the Credit Derivatives Definitions shall be amended accordingly.

  • Scheduled Delivery Date means the Date on which the Seller is required to start delivering the power at the Delivery Point as per the terms and conditions of the PPA;

  • Final Conversion Date means 5:00 p.m. in New York City, New York on the earlier to occur following the IPO of (i) the first Trading Day falling on or after the date on which the outstanding shares of Class B Common Stock represent less than ten percent (10%) of the aggregate number of shares of the then outstanding Class A Common Stock and Class B Common Stock, (ii) the tenth (10th) anniversary of the IPO or (iii) the date specified by affirmative vote of the holders of a majority of the outstanding shares of Class B Common Stock, voting as a single class.

  • Delivery Time means the time for Delivery stated in the Purchase Order.

  • Initial Conversion Price has the meaning specified in Section 13.01.

  • Issuance Notice means a written notice delivered to the Agent by the Company in accordance with this Agreement in the form attached hereto as Exhibit A that is executed by its Chief Executive Officer, President or Chief Financial Officer.

  • Maximum Deliverable Number means the number of Shares set forth as such in Annex B to this Confirmation. Counterparty represents and warrants to Dealer (which representation and warranty shall be deemed to be repeated on each day from the date hereof to the Settlement Date or, if Counterparty has elected to deliver any Payment Shares hereunder in connection with a Special Settlement, to the date on which resale of such Payment Shares is completed (the “Final Resale Date”)) that the Maximum Deliverable Number is equal to or less than the number of authorized but unissued Shares of Counterparty that are not reserved for future issuance in connection with transactions in such Shares (other than the transactions under this Confirmation) on the date of the determination of the Maximum Deliverable Number (such Shares, the “Available Shares”). In the event Counterparty shall not have delivered the full number of Shares otherwise deliverable as a result of this paragraph 5 (the resulting deficit, the “Deficit Shares”), Counterparty shall be continually obligated to deliver, from time to time until the full number of Deficit Shares have been delivered pursuant to this paragraph, Shares when, and to the extent that, (i) Shares are repurchased, acquired or otherwise received by Counterparty or any of its subsidiaries after the date hereof (whether or not in exchange for cash, fair value or any other consideration), (ii) authorized and unissued Shares reserved for issuance in respect of other transactions prior to such date which prior to the relevant date become no longer so reserved or (iii) Counterparty additionally authorizes any unissued Shares that are not reserved for other transactions. Counterparty shall promptly notify Dealer of the occurrence of any of the foregoing events (including the number of Shares subject to clause (i), (ii) or (iii) and the corresponding number of Shares to be delivered) and promptly deliver such Shares thereafter.

  • Opt-Out Deadline means the deadline set by the Court for the timely submission of requests by Settlement Class Members to be excluded from the Settlement Class.

  • Drop Dead Date has the meaning set forth in Section 9.01(b)(i).

  • Notice of Conversion/Extension means the written notice of conversion of a LIBOR Rate Loan to an Alternate Base Rate Loan or an Alternate Base Rate Loan to a LIBOR Rate Loan, or extension of a LIBOR Rate Loan, in each case substantially in the form of Exhibit 1.1(f).

  • Initial Offer Price means the initial price payable for a Share as specified in the relevant Supplement for each Fund.

  • Notice Deadline means 2.30 p.m. (Dublin time), provided that the Notice Deadline in respect of any Series of ETP Securities may be adjusted by agreement between the Issuer and the Margin Loan Provider with effect from the fifth calendar day following the date on which notice of such adjustment is given to the holders in accordance with Condition 17.