Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Special Damages has the meaning specified in Section 11.21.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Product Liability means any liability, claim or expense, including but not limited to attorneys’ fees and medical expenses, arising in whole or in part out of a breach of any express or implied product warranty by the Company, strict liability in tort, negligent manufacture of product, negligent provision of services, product recall, or any other allegation of liability arising from the design, testing, manufacture, packaging, labeling (including instructions for use), or sale of products.
Property damage means physical injury to, destruction of, or loss of use of tangible property.
Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:
Direct Damage has the meaning given to it in clause 26.2;
Cover Damages means, with respect to any Delivery Failure, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 hereof, multiplied by the quantity of that Delivery Failure, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Indemnity Obligations means all obligations of the Company to Indemnitee under this Agreement, including the Company’s obligations to provide indemnification to Indemnitee and advance Expenses to Indemnitee under this Agreement.
Consequential Loss means indirect or consequential loss or damage such as, but not limited to, loss of contract, bargain, expectation, opportunity, profit, production, revenue, anticipated cost reduction or interest payable howsoever caused, arising out of or in connection with this Contract.
Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, members, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors.
Indemnification Obligation means any existing or future obligation of any Debtor to indemnify current and former directors, officers, members, managers, sponsors, agents or employees of any of the Debtors who served in such capacity, with respect to or based upon such service or any act or omission taken or not taken in any of such capacities, or for or on behalf of any Debtor, whether pursuant to agreement, letters, the Debtors’ respective memoranda, articles or certificates of incorporation, corporate charters, bylaws, operating agreements, limited liability company agreements, or similar corporate or organizational documents or other applicable contract or law in effect as of the Effective Date.
Products Liability means:Your legal liability in respect of Personal Injury and/or Property Damage caused by or arising out of any Products or the reliance upon a representation or warranty made at any time with respect to such products; but only where such Personal Injury and/or Property Damage occurs away from premises owned or leased by or rented to You and after physical possession of such products has been relinquished to others.
Accidental Damage means physical damage, breakage or failure of Your Covered Equipment due to an unforeseen and unintentional event occurring either due to handling (e.g., dropping the Covered Equipment or through liquid contact) or due to an external event (e.g., extreme environmental or atmospheric conditions). The damage must affect the functionality of Your Covered Equipment, which includes cracks to the display screen that affect the visibility of the display.
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Actual Damages has the meaning set forth in Section 12.4(C).
Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.
Indemnification Cap has the meaning set forth in Section 9.4(a).
Bodily injury means bodily injury, sickness or disease sustained by a person, including death resulting from any of these at any time.
Severe property damage means substantial physical damage to property, damage to the treatment facilities which would cause them to become inoperable, or substantial and permanent loss of natural resources which can reasonably be expected to occur in the absence of a bypass. Severe property damage does not mean economic loss caused by delays in production.
Environmental Damage means any material injury or damage to persons, living organisms or property or any material pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
Liability Cap has the meaning ascribed to it in paragraph 1 of Schedule 9;
Seller Damages shall have the meaning given to such term in Section 14.3.