Phase I Lease Commencement Date definition

Phase I Lease Commencement Date that is the later to occur of (i) six (6) months after the date on which Landlord has delivered possession of the Phase I Premises to Tenant in the “Delivery Condition”, as that term is defined in Section 1 of Exhibit B attached hereto and (ii) October 1, 2018, provided, however, that (a) in the event that the Delivery Condition for the Phase I Premises is not achieved by October 1, 2018, the six (6) month period referenced in clause (i) above shall be extended by one (1) day for each day after such date until the date that the Delivery Condition is achieved, and (b) in no event shall the Phase I Lease Commencement Date occur until Landlord has caused the “Final Condition” of the Phase I Premises to occur, as that term is defined in Section 1 of Exhibit B attached hereto.
Sample 1Sample 2
Phase I Lease Commencement Date shall be December 1, 2019. The "Phase II Lease Commencement Date" shall be the date that occurs one hundred twenty (120) days following the Phase II Delivery Date (as that term is defined in Section 1 of the Work Letter). The Phase II Delivery Date shall not occur prior to May 1, 2020 without Tenant's prior written consent.
Sample 1
Phase I Lease Commencement Date shall be the earlier of seven (7) months following the Phase I Possession Date, or upon Xxxxxx’s occupancy of the Phase I Premises for the conduct of its business.
Sample 1

Examples of Phase I Lease Commencement Date in a sentence

  • Mitch and his team worked with the vendor to replace the failed Liebert unit serving the Server room at the PSB approved by Resolution 193-20.

  • If the Phase I Lease Commencement Date shall be the first day of a calendar month, then the day immediately preceding the fifteenth (15th) anniversary of the Phase I Lease Commencement Date; or if the Phase I Lease Commencement Date shall be other than the first day of a calendar month, then the last day of the calendar month in which the fifteenth (15th) anniversary of the Phase I Lease Commencement Date occurs.

  • Tenant shall deliver certificates evidencing such policies and applicable endorsements which meet the requirements of this Article 10 to Landlord on or before (I) the earlier to occur of: (x) the Phase I Lease Commencement Date, and (y) the date Tenant and/or its employees, contractors and/or agents first enter a Phase of the Premises for occupancy, construction of improvements, alterations, or any other move-in activities, and (II) five (5) business days after the renewal of such policies.

  • Approximately eleven (11) years and eight (8) months from the "Phase I Lease Commencement Date", as defined below.

  • We have a full range of faculty covering all major research areas in computer scienceand boasts a thriving PhD program that attracts the brightest students from the region and beyond.

  • Landlord shall install four (4) dual electric vehicle charging stations in the Project, at a location determined by Landlord in its reasonable discretion, the installation of which shall be at Landlord's sole cost and expense, prior to the Phase I Lease Commencement Date.

  • Tenant may not install Tenant's Signage until after the occurrence of the first Lease Commencement Date that occurs immediately following the Phase I Lease Commencement Date.

  • Subject to the terms of this Section 29.18, commencing on the Phase I Lease Commencement Date and during the Lease Term, Tenant shall have the right to rent from Landlord the number of unreserved parking passes set forth in Section 5 of the [535 Mission Street] Summary, which parking passes shall pertain to the Project parking facility.

  • The L-C Amount shall not be reduced during that period commencing on the Phase I Lease Commencement Date and expiring on September 30, 2019 (the “Fixed Period”).

  • Landlord shall use commercially reasonable efforts to cause the Phase I Lease Commencement Date to occur by October 15, 2014.


More Definitions of Phase I Lease Commencement Date

Phase I Lease Commencement Date. The earlier to occur of (i) the date upon which Tenant first commences to conduct business in any portion of the Phase I Premises, and (ii) the date that is three (3) months after the date on which Landlord has delivered possession of the entirety of the Phase I Premises to Tenant, which delivery date is anticipated to be July 1, 2017."Phase II Lease Commencement Date": The earlier to occur of (i) the date upon which Tenant first commences to conduct business in any portion of the Phase II Premises, and (ii) the date that is three (3) months after the date on which Landlord has delivered possession of the entirety of the Phase II Premises to Tenant, which delivery date is anticipated to be August 1, 2017.The Phase I Lease Commencement Date and the Phase II Lease Commencement Date may be referred to herein, individually or collectively, as the "Lease Commencement Date".
Sample 1

Related to Phase I Lease Commencement Date

  • Lease Commencement Date has the meaning specified in Section 3.2 of the Master Lease.

  • Rent Commencement Date means the Commencement Date.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Billing Commencement Date means the earlier of:

  • Commencement Date means the date of this Agreement;

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Payment Commencement Date means the date payments of amounts deferred begin pursuant to Article III, Section 6.

  • Loan Commencement Date means, with respect to each Growth Capital Loan: (a) the first day of the first full calendar month following the Borrowing Date of such Loan if such Borrowing Date is not the first day of a month; or (b) the same day as the Borrowing Date if the Borrowing Date is the first day of a month.

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Pay Out Commencement Date means the date on which a Trust Pay Out Event is deemed to occur pursuant to Section 9.01 of the Agreement or a Series 2001-D Pay Out Event is deemed to occur pursuant to Section 7 hereof.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • commencement day means the day on which the State Administrative Tribunal (Conferral of Jurisdiction) Amendment and Repeal Act 2004 Part 2 Division 21 comes into operation;

  • Offering Commencement Date means the first day of each Offering Period.

  • Recommencement Date As defined in Section 6(d) hereof.

  • Employment Commencement Date means the date on which the Employee first performs an Hour of Service.

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Accumulation Commencement Date means January 1, 2021, or such later date as the Calculation Agent on behalf of the Issuer determines in accordance with Section 2.11 hereof.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.

  • Term Commencement Date shall be the later of (i) November 1, 2006 or (ii) the date on which Landlord’s Work is Substantially Complete (or the date on which Landlord’s Work would have been Substantially Complete absent Tenant Delay or Force Majeure (as defined below)); provided, however, that if the Term Commencement Date is not the first day of a calendar month, then the first lease year shall be extended through the last day of the calendar month in which the first 12-month period expires, and Rent for the additional period at the end of the first lease year shall be payable at the rate for the 12th month of the Term. “Force Majeure” means accident; breakage; repair; governmental regulation, moratorium or other governmental action. The “Term Expiration Date” shall be the day immediately preceding the seventh (7th) anniversary of the Term Commencement Date, provided that if such preceding day is not the last day of a calendar month, then the Term Expiration Date shall be the last date of the calendar month in which such preceding day occurs. Landlord and Tenant shall each execute and deliver to the other written acknowledgment of the actual Term Commencement Date and the Term Expiration Date when such are established, and shall attach it to this Lease as Exhibit B. Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.